...final payment under the contract), notifies the owner in writing of the causes of delay. The owner shall ascertain the facts and the extent of the delay...judgment, the findings of fact justify such an extension. His findings of fact shall be final and conclusive on the parties, subject only to appeal as the remedies...

...officer in writing of the causes of delay. The contracting officer shall ascertain the facts and trie extent of the delay and extend the time for completing...justify such an extension, and his findings of fact thereon shall be final and conclusive on the parties hereto, subject only to appeal by the architect-engineer...

...Contractor's right to proceed, the resulting damage will consist of such liquidated damages until the work ii completed or accepted. (d) The Contractor's right...his judgment, the findings of fact justify such an ex* tension, and his findings of fact shall be final and conclusive on the parties, subject only to...

...the Contractor and Chapter 1 — Federal Procurement Regulations (b) Page 2 oí Standard Form 23-A. such subcontractors or suppliers; and (2) The Contractor,...the parties, subject only to appeal as provided in Clause 6 of these General Provisions. (e) If, after notice of termination of the Contractor's right...

...control and without the fault or negligence of both the Contractor and (b) Page 2 of Standard Form 23-A. such subcontractors or suppliers; and (2) The Contractor,...his judgment, the findings of fact justify such an oxtension, and his findings of fact shall be final and conclusive on the parties, subject only to appeal...

...without the fault or negligence of both the Contractor and such subcontractors or suppliers; and (il) The Contractor, within 10 days from the beginning...when, in his judgment, the findings of fact justify Buoh an extension, and his findings of fact shall be final and conclusive on the parties, subject only...

...without the fault or negligence of both the Contractor and such subcontractors or suppliers; and (II) The Contractor, within 10 days from the beginning...and extend the time for completing the work when, In bis Judgment, the findings of fact Justify such an extension, and his findings of fact shall be final...

...days from the beginning of any such delay (unless the Contracting officer grants a further |*>riod of time before the date of final payment under the...such an extension, and his findings of fact shall IM> final and conclusive on the parties, subject only to appeal as provided in Clause 0 of these General...

...Contractor, within 10 days from the beginning of any such delay (unless the Contracting Officer grant* a further period of time before the date of final...the findings of fact justify such an extension. And hlH findings of fact shall be final and conclusive on the parties, subject only to appeal as provided...

...shall grant a further period of time prior to the date of final settlement of the contract, notify the Contracting Officer in writing of the causes of...fact shall be final and conclusive on the parties hereto, subject only to appeal as provided in the clause of this contract entitled "Disputes." (d)...