The Code of Federal Regulations of the United States of AmericaU.S. Government Printing Office, 1975 - Administrative law The Code of Federal Regulations is the codification of the general and permanent rules published in the Federal Register by the executive departments and agencies of the Federal Government. |
From inside the book
Results 6-10 of 100
Page 81
... delivered under this contract or termination of this contract , whichever is later , the delivery of any technical data or computer software item identified in this contract as " deferred delivery " data or computer software . The ...
... delivered under this contract or termination of this contract , whichever is later , the delivery of any technical data or computer software item identified in this contract as " deferred delivery " data or computer software . The ...
Page 82
... delivered under this contract , is not delivered within the time specified by this contract or is deficient upon delivery ( including having restrictive markings not specifically authorized by this contract ) , the Contracting Officer ...
... delivered under this contract , is not delivered within the time specified by this contract or is deficient upon delivery ( including having restrictive markings not specifically authorized by this contract ) , the Contracting Officer ...
Page 83
... delivered under this contract falls within the definition of limited rights data . ( End of provision ) ( k ) Rights in Technical Data - Major Systems and Subsystems Contracts . In accordance with 9–202.2 ( f ) ( 4 ) , the following ...
... delivered under this contract falls within the definition of limited rights data . ( End of provision ) ( k ) Rights in Technical Data - Major Systems and Subsystems Contracts . In accordance with 9–202.2 ( f ) ( 4 ) , the following ...
Page 84
... delivered under this contract or the termination of this contract , order any technical data or computer software ... deliver such technical data of a subcontractor and pertaining to an item obtained from him shall expire three ( 3 ) ...
... delivered under this contract or the termination of this contract , order any technical data or computer software ... deliver such technical data of a subcontractor and pertaining to an item obtained from him shall expire three ( 3 ) ...
Page 86
... delivered hereunder only when authorized by the terms of the " Rights in Technical Data and Computer Software " clause of this contract . Such procedures shall be in writing . The Con- tractor shall also maintain a quality assurance ...
... delivered hereunder only when authorized by the terms of the " Rights in Technical Data and Computer Software " clause of this contract . Such procedures shall be in writing . The Con- tractor shall also maintain a quality assurance ...
Other editions - View all
Common terms and phrases
accepted accordance agreement amount applicable approval Architect-Engineer ASPR authorized award bond Buy American Act certified claim clause therein completion computer software contract price Contracting Officer Contractor agrees cordance Cost Accounting Standards Cost or Pricing damage DD Form default Defense delivered delivery Department of Defense determined End of clause equipment equitable adjustment excess Executive Order 11375 extent Facilities fixed-price following clause furnished future contract Government property hereunder insert the clause insert the following invoice Jewel Bearings liability license materials ment modification negotiated Notice of Termination offeror otherwise paid paragraph performance period Pricing Data prime contractor prior procedures production Program progress payments proposal Puerto Rico purchase pursuant quantity rates reasonable receipt Regulation reimbursed request Schedule Section settlement shipment small business concerns specified subcontract Subject Invention submitted supplies or services surety technical data thereof tion tractor unit price VECP
Popular passages
Page 53 - The decision of the Secretary or his duly authorized representative for the determination of such appeals shall be final and conclusive unless determined by a court of competent jurisdiction to have been fraudulent, or capricious, or arbitrary, or so grossly erroneous as necessarily to imply bad faith, or not supported by substantial evidence.
Page 53 - Disputes" clause does not preclude consideration of law questions in connection with decisions provided for in paragraph (a) above; provided, that nothing in this contract shall be construed as making final the decision of any administrative official, representative, or board on a question of law.
Page 324 - USC 15), if this contract provides for payments aggregating $1,000 or more, claims for moneys due or to become due the Contractor from the Government under this contract may be assigned to a bank, trust company, or other financing institution, Including any Federal lending agency, and may thereafter be further assigned and reassigned to any such Institution. Any such assignment or reassignment shall cover all amounts payable under this contract and not already paid, and shall not be made to more...
Page 42 - Where the cost of property made obsolete or excess as result of a change is included in the Contractor's claim for adjustment, the Contracting Officer shall have the right to prescribe the manner of disposition of such property. Failure to agree to any adjustment shall be a dispute concerning a question of fact within the meaning of the clause of this contract entitled "Disputes".
Page 265 - Invention or discovery" includes any art, machine, manufacture, design, or composition of matter, or any new and useful improvement thereof, or any variety of plant, which is or may be patentable under the patent laws of the United States of America or any foreign country.
Page 321 - Officer grants a further period of time before the date of final payment under the contract), notifies the Contracting Officer in writing of the causes of delay. The Contracting Officer shall ascertain the facts and the extent of the delay and extend the time for completing the work when, in his judgment, the findings of fact justify such an extension...
Page 102 - CONCERNS (JAN. 1958) (a) It Is the policy of the Government as declared by the Congress that a fair proportion of the purchases and contracts for supplies and services for the Government be placed with small business concerns. (b) The Contractor agrees to accomplish the maximum amount of subcontracting to small business concerns that the Contractor finds to be consistent with the efficient performance of this contract. (b) The "Small Business Subcontracting Program...
Page 561 - In this certification, the term "segregated facilities" means any waiting rooms, work areas, rest rooms and wash rooms, restaurants and other eating areas, time clocks, locker rooms and other storage or dressing areas, parking lots, drinking fountains, recreation or entertainment areas, transportation, and housing facilities provided for employees which are segregated by explicit directive or are In fact segregated on the basis of race, creed, color, or national origin, because of habit, local custom...
Page 58 - (5) The contractor will furnish all information and reports required by Executive Order No. 11246 of September 24, 1965, and by the rules, regulations, and orders of the Secretary of Labor, or pursuant thereto, and will permit access to his books, records, and accounts by the contracting agency and the Secretary of Labor for purposes of investigation to ascertain compliance with such rules, regulations, and orders. "(6) In the event of the contractor's noncompliance with the nondiscrimination clauses...
Page 303 - Government Property shall not be affected by the incorporation or attachment thereof to any property not owned by the Government, nor shall such Government Property, or any part thereof, be or become a fixture or lose its identity as personalty by reason of affixation to any realty.