The Code of Federal Regulations of the United States of AmericaU.S. Government Printing Office, 1977 - Administrative law The Code of Federal Regulations is the codification of the general and permanent rules published in the Federal Register by the executive departments and agencies of the Federal Government. |
From inside the book
Results 6-10 of 98
Page 38
... ERDA , and no substantial involvement is anticipated between ERDA and the recipient during performance of the contemplated activity . ERDA'8 role is that of supporting the grantee's project rather than satisfy- ing a specific ERDA ...
... ERDA , and no substantial involvement is anticipated between ERDA and the recipient during performance of the contemplated activity . ERDA'8 role is that of supporting the grantee's project rather than satisfy- ing a specific ERDA ...
Page 47
... ERDA may receive and evaluate the required information as a condition precedent to award . Disclosure Statement Regarding Organizational Conflicts of Interest Pursuant to ERDA - PR Subpart 9-1.54 , it is ERDA policy to avoid situations ...
... ERDA may receive and evaluate the required information as a condition precedent to award . Disclosure Statement Regarding Organizational Conflicts of Interest Pursuant to ERDA - PR Subpart 9-1.54 , it is ERDA policy to avoid situations ...
Page 48
... ERDA regarding ERDA's plans or programs which is not available to interested industrial firms , should not be permitted to compete with such firms for work relating to such plans or programs . ( b ) Development contractors generally ...
... ERDA regarding ERDA's plans or programs which is not available to interested industrial firms , should not be permitted to compete with such firms for work relating to such plans or programs . ( b ) Development contractors generally ...
Page 49
... ERDA request specifica- tions or data with respect to a product sold to ERDA , even though the specifications or data may have been paid for separately or in the price of the product . ( 2 ) Contractors acting as industry ...
... ERDA request specifica- tions or data with respect to a product sold to ERDA , even though the specifications or data may have been paid for separately or in the price of the product . ( 2 ) Contractors acting as industry ...
Page 74
... ERDA.Contract- ing officers shall be held accountable for books of Standard Form 44 issued to them . Heads of ... ERDA order forms . ERDA Standard Order Form 103 shall be used in lieu of Standard Form 147. Standard Form 36 ( Continuation ...
... ERDA.Contract- ing officers shall be held accountable for books of Standard Form 44 issued to them . Heads of ... ERDA order forms . ERDA Standard Order Form 103 shall be used in lieu of Standard Form 147. Standard Form 36 ( Continuation ...
Other editions - View all
Common terms and phrases
accordance additional Administration agency or designee agreement amended amount applicable appropriate approval Article Atomic Energy Act authority award basis bids Bureau of Alcohol Buy American Act classified information clause set construction contracting officer copy cost-type contractors CPSR criteria determination employees equipment ERDA contract ERDA-PR ERDA's evaluation extent facilities Federal field office fixed-price FPMR funds furnished Government Headquarters Heads of procuring indemnity Insert the clause labor license material ment modifications multiyear negotiation notice nuclear obtained OFCCP offeror onsite operating option paragraph patent counsel Patent Rights clause payment performance period personnel prior procuring activity program office proprietary data pursuant regulations rental reports request responsible Rights in Technical Scope of subpart senior procurement official small business solicitation special nuclear material specific standards subcontracts subject invention submitted supplies technical data termination tion Tobacco and Firearms tract unsolicited proposal waiver
Popular passages
Page 239 - Contractor shall be afforded an opportunity to be heard and to offer evidence in support of its appeal. Pending final decision of a dispute hereunder, the Contractor shall proceed diligently with the performance of the contract and in accordance with the Contracting Officer's decision. (b) This "Disputes...
Page 583 - Secretary or his delegate, under any of the following methods: (1) the straight line method, (2) the declining balance method, using a rate not exceeding twice the rate which would have been used had the annual allowance been computed under the method described in paragraph (1).
Page 260 - Contractor was not in default pursuant to (1), or that the Contractor's failure to perform or to make progress in performance is due to causes beyond the control and without the fault or negligence of the Contractor pursuant to the provisions of...
Page 266 - For the purposes of this section, the use or manufacture of an invention described in and covered by a patent of the United States by a contractor, a subcontractor, or any person, firm, or corporation for the Government and with the authorization or consent of the Government, shall be construed as use or manufacture for the United States.
Page 589 - A release discharging the Government, its officers, agents, and employees from all liabilities, obligations, and claims arising out of or under this contract, subject only to the following exceptions...
Page 232 - Provided, however. That the Contracting Officer, if he decides) that the facts justify such action, may receive and act upon any such claim asserted at any time prior to final payment under this contract. Failure to agree to any adjustment shall be a dispute concerning a question of fact within the meaning of the clause of this contract entitled "Disputes.
Page 239 - That any such decision shall be final and conclusive unless the same is fraudulent or capricious or arbitrary or so grossly erroneous as necessarily to imply bad faith or is not supported by substantial evidence. In connection with any appeal proceeding under this clause, the Contractor shall be afforded an opportunity to be heard and to offer evidence in support of his appeal.
Page 270 - The foregoing Indemnity shall not apply unless the Contractor shall have been Informed as soon as practicable by the Government of the suit or action alleging such Infringement, and shall have been given such opportunity as is afforded by applicable laws, rules, or regulations to participate in the defense thereof; and further, such...
Page 242 - If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted by an act of the Contracting Officer in the administration of...
Page 257 - Provisions. 5. TERMINATION FOR DEFAULT— DAMAGES FOR DELAY— TIME EXTENSIONS (a) If the Contractor refuses or fails to prosecute the work, or any separable part thereof, with such diligence as will insure its completion within the time specified in this contract, or any extension thereof, or fails to complete said work within such time...