« PreviousContinue »
§ 12-7.150-5 Notice of readiness for in
three or more than ten times the cost incurred by the Contractor in providing any such gratuities to any such officer or employee.
(c) The rights and remedies of the Government provided in this clause shall not be exclusive and are in addition to any other rights and remedies provided by law or under this contract.
(End of clause)
§ 12-7.150-2 New materials.
NOTICE OF READINESS FOR INSPECTION (a) If the contract provides for inspection at the Contractor's plant, the Contractor shall give the Contracting Officer at least 5 days' (unless a longer period is specified in the Schedule) written or telegraphic notice of readiness for inspection in cases where no security clearance is required for the Government Inspector. In cases where security clearance is required for the Government Inspector to obtain access to the Contractor's plant, the Contractor shall so advise the Contracting Officer and give at least days' notice of readiness for inspection.
(b) In those cases where a Government Inspector is assigned to the plant for the purpose of conducting continuous inspections of production on the contract, and he is otherwise kept informed of the progress of production, the written notices specified in (a) above need not be given.
Except as to any supplies or components which the contract specifically provides need not be new, all supplies and components to be provided under this contract shall be new (not used or reconditioned, and not of such age or so deteriorated as to impair their usefulness or safety), of current production, and of the most suitable grade for the purpose intended. If at any time during the performance of this contract the Contractor believes that the furnishing of supplies or components which are not new is necessary or desirable, he shall notify the Contracting Officer immediately, in writing, including the reasons therefor and proposing any conside ation which will flow to the Government if authorization to use such supplies is granted.
(End of clause)
8 12–7.150–6 Definition of delivery terms.
DEFINITION OF DELIVERY TERMS
(End of clause)
& 12-7.150-3 Priorities, allocations, and al.
The meaning of delivery terms used in this contract such as “f.o.b. origin”, “f.o.b. destination", "f.a.s. vessel, port of shipment”, and other delivery terms shall be as. those terms are defined in subpart 1-19.3 of the Federal Procurement Regulations (41 CFR 1-19.3).
(End of clause)
PRIORITIES, ALLOCATIONS, AND ALLOTMENTS
The Contractor shall follow the provisions of DMS Reg. 1 and all other applicable regulations and orders of the Business and Defense Services Administration in obtaining controlled materials and other products and materials required for the performance of this contract.
(End of clause)
§ 12-7.150-7 Evidence of delivery.
EVIDENCE OF DELIVERY
8 12-7.150-4. Interpretation or modifica
INTERPRETATION OR MODIFICATION No oral statement of any person, and no written statement of anyone other than the Contracting Officer, or his authorized representative designated in accordance with section 12-1.402-50 of the DOT Procurement Regulations (41 CFR 12-1.402-50), acting within the limits of his authority specified in such designation, shall modify or otherwise affect any provision of the contract.
(End of clause)
When the contract delivery point is “f.o.b. origin", evidence of delivery shall be submitted with invoices. In the case of freight or express shipment, this evidence shall be in the form of memorandum copies of Bills of Lading duly receipted by the carrier. In the case of parcel post shipments this evidence shall be Post Office Certificate of Mailing, Form 3817. If the invoice submitted for payment is not accompanied by evidence of delivery, discounts for prompt payment will be computed from date of receipt of such evidence of delivery, when the contract delivery point is other than "f.o.b. origin", evidence of delivery will be obtained from the consignee.
(End of clause)
& 12-7.150-8 Withholding payment for
nondelivery of data. When the contract requires data to be furnished, its timely delivery is important. The clause set forth below is designed to insure timely delivery of complete and current data. The clause provides for a withholding of a certain percentage of the contract price, but the contracting officer may specify a lesser amount in the schedule if circumstances warrant.
construed as a waiver by the Government of any rights or remedies to which it is entitled by law or pursuant to provisions of this contract. Failure to give such notice, however, may be grounds for denial of any request for an extension of the delivery schedule because of such delay.
(b) The Contractor agrees to insert the substance of this clause, including this paragraph (b), in any subcontract hereunder; except that each such subcontract shall provide that in the event its timely performance is delayed or threatened by delay, the subcontractor shall immediately notify his next higher tier subcontractor, or the prime contractor, as the case may be, of all relevant information with respect thereto.
WITHHOLDING PAYMENT FOR NONDELIVERY OF
(b) The withholding of any sums pursuant to this clause shall not be construed as, or constitute in any manner, a waiver by the Government of the Contractor's obligation to furnish the data required under this contract. In the event the Contractor fails to furnish these items, the Government shall have those rights and remedies provided by law and pursuant to this contract in addition to, and not in lieu of the sums withheld in accordance with this clause.
(End of clause)
8 12-7.150-9 Notice of delays.
AUTHORIZATION AND CONSENT The Government hereby gives its authorization and consent (without prejudice to any rights of indemnification) for all use and manufacture, in the performance of this contract or any part hereof or any amendment hereto or any subcontract hereunder (including any lower tier subcontract) of any invention described in and covered by a patent of the United States (i) embodied in the structure or composition of any article the delivery of which is accepted by the Government under this contract, or (ii) utilized in the machinery, tools, or methods the use of which necessarily results from compliance by the Contractor or the using subcontractor with (a) specifications or written provisions now or hereafter forming a part of this contract, or (b) specific written instructions given by the Contracting Officer directing the manner of performance. The entire liability to the Government for infringement of a patent of the United
NOTICE OF DELAYS
(a) Whenever the Contractor encounters any difficulty which is delaying or threatens to delay the timely performance of this contract (including actual or potential labor disputes), the Contractor shall immediately give notice thereof in writing to the Contracting Officer, stating all relevant information with respect thereto. Such notice shall not in any way constitute a basis for an extension of the delivery schedule or be
States shall be determined solely by the provisions of the indemnity clauses, if any, included in this contract or any subcontract hereunder (including any lower tier subcontract), and the Government assumes liability for all other infringement to the extent of the authorization and consent hereinabove granted.
(End of clause)
§ 12-7.150-12 Background patents (li
cense). Insert the following clause under the conditions prescribed in DOTPR 129.150.
BACKGROUND PATENTS (LICENSE)
(a) “Product” as used herein means a process, machine article of manufacture, or composition of matter the same as, or substantially the same as, that worked on under the contract.
(b) "Background patent” as used herein means any United States patent, under which the Contractor has the right to li. cense others, and which covers the manufacture, use, or sale of any product.
(c) When the Secretary determines:
(1) That a product is required by members of the public in the interest of the public health, safety, or welfare; and, (2) That neither the Contractor, nor any other person deriving rights from his patents, has produced the product at a reasonable price, in sufficient quantity, and at a level of quality to meet public needs; the Contractor shall, on written application, issue appropriate licenses to others under any Background Patent on reasonable terms, such licenses to be restricted to the production, sale, and use of the product
(d) When the Secretary has made the determination set forth in (c) above, the Contractor (or those deriving rights from the Contractor) shall not seek injunctive relief to enforce a Background Patent without:
(1) Previously advising the General Counsel, Office of the Secretary, Department of Transportation;
(2) Granting the Government the right to intervene in the injunction proceeding; and
(3) Disclosing the commitment set out in this clause to the court from which the injunction is sought.
§ 12–7.151-1 Patent indemnity.
In accordance with DOTPR 129.152-1 and DOTPR 12-9.152-3, insert the following clause or clauses under the conditions prescribed therein.
(a) Patent indemnity. If the amount of this contract is in excess of $10,000, the Contractor shall indemnify the Government and its officers, agents, and employees against liability, including costs, for infringement of any United States letters patent (except letters patent issued upon an application which is now or may hereafter be kept secret or otherwise withheld for issue by order of the Government) arising out of the manufacture or delivery of supplies or out of construction, alteration, modification, or repair of real property (hereinafter referred to as “construction work”) under this contract, or out of the use or disposal by or for the account of the Government of such supplies or construction work. The foregoing indemnity shall not apply unless the Contractor shall have been informed as soon as practicable by the Government of the suit or action alleging such infringement, and shall have been given such opportunity as is afforded by applicable laws, rules, or regulations to participate in the defense thereof; and further, such indemnity shall not apply to: (i) an infringement resulting from compliance with specific written instructions of the Contracting Officer directing a change in the supplies to be delivered or in the materials or equipment to be used, or directing a manner of performance of the contract not normally used by the Contractor; (ii) an infringement resulting from addition to, or change in, such supplies or components furnished or construction work performed which addition or change was made subsequent to delivery or performance by the Contractor; or (iii) a claimed infringement which is settled without the consent of the Contractor, unless required by final decree of a court of competent jurisdiction.
(End of clause)
(End of clause) (b) Waiver of indemnity. Any provision of this contract to the contrary notwithstanding, the Government hereby authorizes and consents to use and manufacture, solely in the performance of this contract, of any invention covered by the United States patents identified and listed below, and waives indemnification by the Contractor with respect to such patents: (Identify the patents by number or by other means if more appropriate).
(End of clause)
8 12-7.151 DOTPR clauses to be used
when applicable. The following clauses shall be included in the contract when their use is appropriate.
§ 12-7.151-2 Filing of patent applications.
Insert the following clause under the conditions prescribed in DOTPR 129.154.
shall by separate letter identify by agency and number the contract or contracts which require security classification markings to be placed on the application.
(e) The substance of this clause shall be included in all subcontracts which cover or are likely to cover classified subject matter.
(End of clause)
§ 12-7.151-3 Reporting of royalties (for
eign). Insert the following clause under the conditions prescribed in DOTPR 129.156 (d)(1).
FILING OF PATENT APPLICATIONS (a) Before filing or causing to be filed a patent application in the United States disclosing any subject matter of this contract, which subject matter is classified "Secret" or higher, the Contractor shall, citing the thirty (30) day provision below, transmit the proposed application to the Contracting Officer for determination whether, for reasons of national security, such application should be placed under an order of secrecy or sealed in accordance with the provisions of 35 U.S.C. 181-188 or the issuance of a patent should be otherwise delayed under pertinent United States statutes or regulations; and the Contractor shall observe any instructions of the Contracting Officer with respect to the manner of delivery of the patent application to the United States Patent Office for filing, but the Contractor shall not be denied the right to file such patent application. If the Contracting Officer shall not have given any such instructions within thirty (30) days from the date of mailing or other transmittal of the proposed application, the Contractor may file the application.
(b) The Contractor shall furnish to the Contracting Officer, at the time of or prior to the time when the Contractor files or causes to be filed a patent application in the United States disclosing any subject matter of this contract, which subject matter is classified “Confidential", a copy of such application for determination whether, for reasons of national security, such application should be placed under an order of secrecy or the issuance of a patent should be otherwise delayed under pertinent United States statutes or regulations.
(c) Where the subject matter of this contract is classified for reasons of security, the Contractor shall not file, or cause to be filed in any country, other than in the United States as provided in (a) and (b) of this clause, an application or registration for a patent containing any of said subject matter without first obtaining written approval of the Contracting Officer.
(d) When filing any patent application coming within the scope of this clause, the Contractor shall observe all applicable security regulations covering the transmission of classified subject matter, and shall also promptly furnish to the Contracting Officer the serial number, filing date, and name of country of any such patent application. When transmitting the application to the United States Patent Office, the Contractor
REPORTING OF ROYALTIES (FOREIGN) (a) If this contract is in an amount which exceeds fifty thousand United States dollars ($50,000), the Contractor shall report in writing to the Contracting Officer during the performance of this contract the amount of royalties paid or to be paid by the Contractor directly to others in the performance of this contract. The Contractor shall also: (i) Furnish in writing any additional information relating to such royalties as may be requested by the Contracting Officer, and (ii) insert a provision similar to this clause in any subcontract hereunder which involves an amount in excess of the equivalent of fifty thousand United States dollars ($50,000).
(2) The term “royalties" as used herein refers to any costs or charges in the nature of royalties, license fees, patent or license amortization costs, or the like for the use of or for rights in patents or patent applications.
(End of clause)
8 12-7.151-4 Refund of royalties.
Insert the following clause under the conditions prescribed in DOTPR 129.157
REFUND OF ROYALTIES
(a) The contract price includes certain amounts for royalties payable by the Contractor or subcontractors or both, which amounts have been reported to the Contracting Officer.
(b) The term “royalties" as used in this clause refers to any costs or charges in the nature of royalties, license fees, patent or license amortization costs, or the like, for the use or for rights in patents and patent applications in connection with the performance of this contract or any subcontracts hereunder.
(c) The Contractor shall furnish to the Contracting Officer, before final payment under this contract, a statement of royalties paid or required to be paid in connection with the performance of this contract and subcontracts hereunder together with the reasons therefor.
(d) The Contractor will be compensated for royalties reported under (c) above only to the extent that such royalties were included in the contract price and are determined by the Contracting Officer to be properly chargeable to the Government and allowable to the contract. Therefore, to the extent that any royalties which are included in the contract price are not in fact paid by the Contractor or are determined by the Contracting Officer not to be properly chargeable to the Government and allocable to the contract, the contract price shall be reduced. Repayment or credit to the Government shall be made as the Contracting Officer directs.
(e) If, at any time within three (3) years subsequent to final payment under this contract, the Contractor for any reason is relieved in whole or in part from the payment of the royalties included in the final contract price as adjusted pursuant to paragraph (d) above, the Contractor shall promptly notify the Contracting Officer of that fact and shall reimburse the Government in a corresponding amount.
(f) The substance of this clause, including this paragraph (f), shall be included in any subcontract in which the amount of royalties reported during negotiation of the subcontract exceeds $250.
(b) (1) The Government may duplicate, use, and disclose in any manner and for any purpose whatsoever, and have others to so do, all subject data delivered under this contract.
(2) The Contractor agrees to and does hereby grant to the Government, and to its officers, agents and employees acting within the scope of their official duties, a royaltyfree, non-exclusive, irrevocable license throughout the world, to publish, translate, deliver, perform, dispose of, and to authorize others to so do, all subject data now or hereafter covered by copyright.
(3) The Contractor shall report to the Contracting Officer promptly and in reasonably written detail, each notice or claim of copyright infringement with respect to all subject data delivered under this contract.
(c) Nothing contained in this clause shall imply a license to the Government under any patent or be construed as affecting the scope of any license or other right otherwise granted to the Government under any patent.
(d) The Contractor shall not affix any restrictive markings upon any subject data, and if such markings are affixed, the Government shall have the right at any time to modify, remove, obliterate or ignore any such markings.
(End of clause)
(End of clause)
8 12–7.151–6 Rights in data-title.
Insert the following clause under the conditions prescribed in DOTPR 129.201-1(b). Alterations in the clause may be made under the conditions prescribed in DOTPR 12-9.201-2.
8 12-7.151-5 Rights in data-unlimited
contract clause. Insert the following clause under the conditions prescribed in DOTPR 129.201-1(a). Alterations in the clause may be made under the conditions prescribed in DOTPR 12-9.201-2.
RIGHTS IN DATA-UNLIMITED (a) The term “subject data" as used herein means recorded information, wheth. er or not copyrighted, that is delivered or specified to be delivered under this contract. The term includes graphic or pictorial delin. eations in media such as drawings or photographs; text in specifications or related performance or photographs; design-type documents; machine forms such as punched cards, magnetic tape, or computer memory printouts; and information retained in computer memory. Examples include, but are not limited to, engineering drawings and associated lists, specifications, standards, process sheets, manual, technical reports, catalog item identifications, and related information. The term does not include financial reports, cost analyses, and similar information incidental to contract administration.
RIGHTS IN DATA-TITLE (a) The term “subject data" as used herein means recorded information, whether or not copyrighted, that is delivered or specified to be delivered under this contract. The term includes graphic or pictorial delineations in media such as drawings or photographs; text in specifications or related performance or design-type documents; machine forms such as punched cards, magnetic tape, or computer memory printouts; and information retained in computer memory. Examples include, but are not limited to, engineering drawings and associated lists, specifications, standards, process sheets, manuals, technical reports, catalog item identifications, and related information. The term does not include financial reports, cost analyses, and similar information incidental to contract administration.
(b) All “subject data" first produced in the performance of this contract shall be the sole property of the Government. The Contractor agrees not to assert any rights at