Atomic Energy Commission reports v.3, Volume 3 |
From inside the book
Results 1-5 of 100
Page 227
... contract . Inspection on July 3 , 1963 , showed no change in the status of completion . Accordingly , the contracting officer made demand upon the appellant for liquidated damages in the sum of $ 25,750 . The July 8 , 1963 , demand for ...
... contract . Inspection on July 3 , 1963 , showed no change in the status of completion . Accordingly , the contracting officer made demand upon the appellant for liquidated damages in the sum of $ 25,750 . The July 8 , 1963 , demand for ...
Page 228
... contracting officer's decision herein was rendered on Novem- ber 27 , 1963. Notice of appeal was timely filed by appellant's counsel on December 26 , 1963. Its counsel duly transmitted the complaint which was received on January 13 ...
... contracting officer's decision herein was rendered on Novem- ber 27 , 1963. Notice of appeal was timely filed by appellant's counsel on December 26 , 1963. Its counsel duly transmitted the complaint which was received on January 13 ...
Page 230
... contracting officer's testimony that the facts found in his decision are true was not chal- lenged or refuted on this record . CONCLUSIONS 11. This proceeding is without discovered precedent in contract disputes appeals in that by this ...
... contracting officer's testimony that the facts found in his decision are true was not chal- lenged or refuted on this record . CONCLUSIONS 11. This proceeding is without discovered precedent in contract disputes appeals in that by this ...
Page 233
United States Atomic Energy Commission. that difficulties in the contract performance resulted because the Contracting Officer ... Officer accepted the contract performance on the two wells with deviations greater than 1 ° , but only in ...
United States Atomic Energy Commission. that difficulties in the contract performance resulted because the Contracting Officer ... Officer accepted the contract performance on the two wells with deviations greater than 1 ° , but only in ...
Page 234
... Contracting Officer that : 4 " The information presented on this drawing represents the best information available to the Contracting Officer . " Following that warranty , was the usual exculpatory clause : " No warranty as to the ...
... Contracting Officer that : 4 " The information presented on this drawing represents the best information available to the Contracting Officer . " Following that warranty , was the usual exculpatory clause : " No warranty as to the ...
Common terms and phrases
additional amended amount anhydrite Appellant's application Atomic Energy Act Atomic Energy Commission Atomic Safety Avien Board of Contract boiling water reactor Bokum boron Browns Ferry Buchecker Chairman Churchrock claim Company conclusions Consolidated Edison containment Contract Appeals Contracting Officer Contracting Officer's core cost counsel criteria DOCKET AECBCA documents drilling Electric engineering estimated evidence fault filed fission products fuel Gesellschaft Government ground displacement health and safety Hearing Examiner Initial Decision issuance issues Licensing Board Malibu matters megawatts ment mining nuclear parties petition plant power level PRDC presented pressurized water reactor procedures proceeding proposed facility proposed findings provisional construction permit purchase order pursuant reactor reasonable assurance record regulations Regulatory Staff request Rules of Practice SAEA Safety and Licensing SEABORG Section SEFOR special nuclear material specifications subcontractor submitted technical thermal tion Turberville United uranium
Popular passages
Page 214 - That the right of the contractor to proceed shall not be terminated or the contractor charged with liquidated damages because of any delays in the completion of the work due to unforeseeable causes beyond the control and without the fault or negligence of the contractor...
Page 227 - Subsurface or latent physical conditions at the site differing materially from those indicated in this contract, or (2) unknown physical conditions at the site, of an unusual nature, differing materially from those ordinarily encountered and generally recognized as inhering in work of the character provided for in this contract.
Page 14 - Commission has found that the final design provides reasonable assurance that the health and safety of the public will not be endangered by operation of the facility in accordance with the requirements of the license and the regulations In this chapter.
Page 61 - The facility will operate in conformity with the application as amended, the provisions of the Act, and the rules and regulations of the Commission, and (3) There is reasonable assurance (i) that the activities authorized by the operating license can be conducted without endangering the health and safety of the public...
Page 11 - ... on the basis of the foregoing, there is reasonable assurance that (i) such safety questions will be satisfactorily resolved at or before the latest date stated in the application for completion of construction of the proposed facility and...
Page 193 - Safety features or components, if any, which require research and development have been described by the applicant and the applicant has identified, and there will be conducted a research and development program reasonably designed to resolve any safety questions associated with such features or components...
Page 127 - ... cannot make" necessary licensing or rulemaking determinations — such as that a proposed facility can be constructed and operated without undue risk to the health and safety of the public...
Page 139 - ... described by the applicant and the applicant has identified, and there will be conducted, a research and development program reasonably designed to resolve any safety questions associated with such features or components; and (d) On the basis of the foregoing...
Page 407 - for the protection of all persons supplying labor and material in the prosecution of the work provided "(a) Before any contract, exceeding $2000 in amount, for the construction, alteration, or repair of any public building or public work of the United States...
Page 87 - ... d. No license under this section may be given to any person for activities which are not under or within the jurisdiction of the United States, except for the export of production or utilization facilities under terms of an agreement for cooperation arranged pursuant to section 123 or except under the provisions of section 109.