Page images
PDF
EPUB

PART 8-TERMINATION OF CONTRACTS

Table of Contents

Subpart 2-General Principles Applicable to the Settlement of Fixed-Price

Type Contracts Terminated for convenience and to the Settlement of all

Terminated Cost-Reimbursement Type Contracts Continued Paragraph

Page 8.206 Duties of Termination Contracting Officer After Issuance of Notice of Termination.

808 8.206-1 Termination Status Report

809 8.206-2 Release of Excess Funds

810 8.206-3 Termination Case File..-..

810 8.206–50 Negotiation and Settlement by the Department

of Defense or Other Government Agency----- 810 8.207 Fraud or Other Criminal Conduct -

810 8.208 Audit of Prime Contract Settlement Proposals and of Subcontract Settlements.

810 8.209 Settlement of Subcontract Claims..

812 8.209-1 Subcontractor's Rights..

812 8.209-2 Prime Contractor's Rights and Obligations.. 812 8.209-3 Settlement Procedure...

812 8.209-4 Authorization for Subcontract Settlements Without Approval or Ratification..--

813 8.209-5 Recognition of Judgments and Arbitration Awards...

815 8.209-6 Delay in Settlement of Subcontractor Claims... 816 8.209–7 Government Assistance in Settlement of Subcontracts.--

816 8.209-8 Assignment of Rights Under Subcontracts..

816 8.210 Settlement Agreements..

817 8.210-1 General...

817 8.210-2 Reserved Items --

817 8.210-3 Government Property--

817 8.210-4 No-Cost Settlement

817 8.210-5 Partial Settlements...

818 8.210–6 Joint Settlement of Two or More Claims.--

818 8.210-7 Settlement by Determination..

818 8.211 Contracting Officer's Negotiation Memorandum.

820 8.212 Review and Approval of Proposed Settlements.

820 8.212-1 Settlement Review Boards..

820 8.212-2 Required Review and Approval.

820 8.212-3 Scope of Review

821 8.212-4 Action by Board.

821 8.212-5 Subcontracts.

821 8.213 Payment.

821 8.213-1 Partial Payments Upon Termination.--

821 8.213-2 Final Payment

823 8.214 Cost Principles Applicable to the Settlement of Research and

Development Contracts With Educational Institutions.-- 824 8.215 Settlement of Unadjusted Contract Changes.

824 8.216 [Reserved]----

824 8.217 Settlement of Terminated Contracts With Incentive Provisions. 824 Subpart 3- Additional Principles Applicable to the Settlement of

Terminated Fixed-Price Type Contracts Paragraph

Page 8.301 General... .

827 8.302 Cost Principles.

827 8.303 Allowance for Profit..

827 8.304 Adjustment for Loss .

828 8.305 Deductions

829 8.306 Completed End Items.

829 8.307 Settlement Proposal..

829 8.307–1 Submission of Settlement Proposals_

829 8.307—2 Bases for Settlement Proposals..

830 8.308 Limitations on Settlements.. .

831 8.309 Equitable Adjustment in Unit Prices Under Fixed-Price Contracts in Cases of Partial Termination.--

831

Subpart 4 Additional Principles Applicable to the Settlement of

Terminated Cost-Reimbursement Type Contracts

8.401 General Considerations..
8.402 Discontinuance of Vouchers...
8.403 Reserved]-

[---
8,404 Procedure After Vouchers Are Discontinued...

8.404–1 Submission of Settlement Proposal
8.404–2 Audit of Settlement Proposal...
8.404–3 Partial Payments.---
8.404-4 Adjustment of Overhead Costs_

8.404–5 Final Settlement... 8.405 Procedure for Partial Termination..

8.405–1 General...
8.405–2 Submission of Settlement Proposal (Fee Only).

8.405-3 Submission of Vouchers
8.406 Adjustment of Fee... .
8.407 Termination for Default ...

833 833 833 833 833 833 833 834 834 834 834 835 835 835 835

Subpart 5 Reserved

Subpart 6Termination for Default

841 841 841

8.600 Scope of Subpart...
8.601 General.....
8.602 Termination of Fixed-Price Supply Contracts for Default.
8.602–1 The Government's Right To Terminate for

Default.
8.602–2 Effect of Termination for Default..
8.602–3 Procedure for Default...
8.602-4 Procedure in Lieu of Termination for Default...
8.602–5 Memorandum by the Contracting Officer.
8.602–6 Repurchase Against Contractor Account -----
8.602-7 Other Damages.---

841 841 842 844 845 845 846

Subpart 6Termination for Default-Continued

Paragraph

Page 8.650 Termination of Fixed-Price Construction Contracts for Default. 846 8.650-1 Termination of the Contractor's Right to Proceed.--

846 8.650-2 Effect of Termination for Default....

846 8.650-3 Preliminary Notice to Surety--

846 8.650-4 Procedures in Case of Default

846 8.650-5 Dealings With Surety-Take Over Agreements... 846. 1 8.650-6 Completion by Another Contractor..

846.3 8.650-7 Procedure in Lieu of Termination for Default.- 846.3 8.650-8 Documentation in Contract File.--.

846.3 8.650-9 Withholding for Labor Violations.

846. 3 8.650–10 Liquidation of Liability -

846.3 8.650–11 Excusable Default..

846, 3

Subpart 7–Clauses 8.700 Scope of Subpart...

847 8.701 Termination Clause for Fixed-Price Contracts.

847 8.701-1 Fixed-Price Type Letter Contracts..

851 8.702 Termination Clause for Cost-Reimbursement Type Contracts.. 854

8.702–1 Cost-Reimbursement Type Letter Contracts.-- 858 8.703 (Reserved)---

861 8.704 Research and Development Contracts With Educational and Other Nonprofit Institutions.

861 8.704-1 Termination Clause.. ...

861 8.704–2 Suggested Clause for Subcontracts..

862 8.705 Short Form Termination Clauses for Fixed-Price Type Contracts..

863 8.705-1 Supply and Service Contracts...

863 8.705–2 Construction Contracts..

863 8.705-50 Research Contracts with Educational and Other Nonprofit Institutions.

863 8.706 Subcontract Termination Clause --

864 8.707 Default Clause for Fixed-Price Supply Contracts...

866, 1 8.708 Excusable Delays Clause for Cost-Reimbursement Type Contracts...

866, 2 8.709 Default Clause for Fixed-Price Construction Contracts... 866. 3 8.710 Default Clause for Fixed-Price Research and Development Contracts.

866; 4

Subpart 8–Forms 8.800 Scope of Subpart.8.801 Notice of Termination.

8.801-1 Telegraphic Notice of Termination. 8.801-2 Letter Notice of Termination.

867 867 867 868

« PreviousContinue »