Code of Federal Regulations: Containing a Codification of Documents of General Applicability and Future Effect as of December 31, 1948, with Ancillaries and IndexU.S. General Services Administration, National Archives and Records Service, Office of the Federal Register, 1979 - Administrative law Special edition of the Federal Register, containing a codification of documents of general applicability and future effect ... with ancillaries. |
From inside the book
Results 1-5 of 100
Page 22
... award , " brand name or equal " descriptions . ( a ) Bids offering products which differ from brand name products ref- erenced in a " brand name or equal " purchase description shall be consid- ered for award where the contracting ...
... award , " brand name or equal " descriptions . ( a ) Bids offering products which differ from brand name products ref- erenced in a " brand name or equal " purchase description shall be consid- ered for award where the contracting ...
Page 23
... award a contract . However , in some cases requests for in- formational or planning purposes may be justified . In such cases the request shall clearly state its purpose , explain- ing that the Government does not intend to award a ...
... award a contract . However , in some cases requests for in- formational or planning purposes may be justified . In such cases the request shall clearly state its purpose , explain- ing that the Government does not intend to award a ...
Page 24
... Award ( Construction , Alteration or Repair ) , and Standard Form 23A , Gen- eral Provisions ( Construction Con ... award or acceptance by the Government , or from date shown on contract docu- ment as effective date of contract ) ; or ...
... Award ( Construction , Alteration or Repair ) , and Standard Form 23A , Gen- eral Provisions ( Construction Con ... award or acceptance by the Government , or from date shown on contract docu- ment as effective date of contract ) ; or ...
Page 25
... award by ( procuring ac- tivity insert calendar date ) . Each delivery date in the delivery schedule set forth herein will be extended by the number of calendar days after the above date that the contract is in fact awarded . Attention ...
... award by ( procuring ac- tivity insert calendar date ) . Each delivery date in the delivery schedule set forth herein will be extended by the number of calendar days after the above date that the contract is in fact awarded . Attention ...
Page 26
... award process as regards time of delivery . These clauses also may be suitably modified for use in negotiated pro- curements where appropriate . ( b ) The following clause may be used where delivery by a particular time is necessary to ...
... award process as regards time of delivery . These clauses also may be suitably modified for use in negotiated pro- curements where appropriate . ( b ) The following clause may be used where delivery by a particular time is necessary to ...
Other editions - View all
Common terms and phrases
accordance adjustment Administration ADPE agreement allocation amended amount ance applicable appropriate assets audit authority award basis bidder business unit Buy American Act cerns clause set cluding contract clause contract price contractor cost ac cost accounting period Cost Accounting Standards cost or pricing curement delivery determination Engineering overhead equipment ernment estimated evaluation executive agencies facilities capital Federal fixed-price furnished G&A expense Government property home office indirect cost Insert the clause invitation for bids jewel bearings July 24 justment labor surplus area material ment negotiated notice offeror overhead paragraph payment pension cost performance prescribed pricing data prime contract prior procedures procuring agency proposal purchase pursuant quired reasonable receipt regulations request set-aside settlement small business concerns solicitation specific subcon subcontract submitted Subpart supplies termination tion tive tracting officer tractor type contracts
Popular passages
Page 312 - The decision of the Secretary or his duly authorized representative for the determination of such appeals shall be final and conclusive unless determined by a court of competent jurisdiction to have been fraudulent, or capricious, or arbitrary, or so grossly erroneous as necessarily to imply bad faith, or not supported by substantial evidence.
Page 341 - Contractor for adjustment under this clause must be asserted within 30 days from the date of receipt by the Contractor of the notification of change : Provided, however, That the Contracting Officer, if he decides that the facts justify such action, may receive and act upon any such claim asserted at any time prior to final Payment under this contract. Failure to agree to any adjustment shall be a dispute concerning a question of fact within the meaning of the clause of this contract entitled "Disputes.
Page 445 - Invention or discovery" includes any art, machine, manufacture, design, or composition of matter, or any new and useful improvement thereof, or any variety of plant, which is or may be patentable under the patent laws of the United States of America or any foreign country.
Page 401 - ... the Government may, by written notice to the contractor, terminate his right to proceed with the work or such part of the work as to which there has been delay. In...
Page 310 - Contracting Officer" means the person executing this contract on behalf of the Government, and any other officer or civilian employee who Is a properly designated Contracting Officer; and the term Includes, except as otherwise provided In this contract, the authorized representative of a Contracting Officer acting within the limits of his authority. (c) 'Except as otherwise provided In this contract, the term "subcontracts" Includes purchase orders under this contract.
Page 312 - ... fraudulent, or capricious, or arbitrary, or so grossly erroneous as necessarily to Imply bad faith, or not supported by substantial evidence. In connection with any appeal proceeding under this clause, the Contractor shall be afforded an opportunity to be heard and to offer evidence In support of Its appeal. Pending final decision of a dispute hereunder, the Contractor shall proceed diligently with the performance of the contract and in accordance with the Contracting Officer's decision. (b)...
Page 327 - Any claim by the Contractor for adjustment under this clause must be asserted within 30 days from the date of receipt by the Contractor of the notification of change: Provided, however, That the Contracting Officer, if he decides that the facts justify such action, may receive and act upon any such claim asserted at any time prior to final payment under this contract.
Page 394 - Contractor under this contract or shall otherwise be credited to the price or cost of the work covered by this contract or paid in such other manner as the Contracting Officer may direct; (8) Complete performance of such part of the work as shall not have been terminated by the Notice of Termination; and (9) Take such action as may be necessary, or as the Contracting Officer may direct, for the protection and preservation of the property related to this contract which Is in the possession of the...
Page 292 - Consequential damages resulting from the seller's breach include (a) any loss resulting from general or particular requirements and needs of which the seller at the time of contracting had reason to know and which could not reasonably be prevented by cover or otherwise; and (b) injury to person or property proximately resulting from any breach of warranty.
Page 445 - To the point of practical application" means to manufacture in the case of a composition or product, to practice in the case of a process, or to operate in the case of a machine, and under such conditions as to establish that the invention is being worked and that its benefits are reasonably accessible to the public.