Cases Decided in the Court of Claims of the United States, Volume 91U.S. Government Printing Office, 1940 - Law reports, digests, etc |
From inside the book
Results 1-5 of 89
Page 22
... tract to install the ducts in controversy , defendant concedes the amount of the claim . The work provided for by Article 32 was let by defendant to the Thomas Plumbing & Heating Company , an independent contractor , and the parties ...
... tract to install the ducts in controversy , defendant concedes the amount of the claim . The work provided for by Article 32 was let by defendant to the Thomas Plumbing & Heating Company , an independent contractor , and the parties ...
Page 27
... tract for liquidated damages was eliminated as the failure to make available the site for building No. 10 delayed the com- pletion of the project to the very last . It is said that the delay on this building did not damage the ...
... tract for liquidated damages was eliminated as the failure to make available the site for building No. 10 delayed the com- pletion of the project to the very last . It is said that the delay on this building did not damage the ...
Page 34
... tract . These items total $ 11,258.32 , for which judgment will be rendered in favor of the plaintiff . It is so ordered . WILLIAMS , Judge ; LITTLETON , Judge ; and WHALEY , Chief Justice , concur . WHITAKER , Judge , took no part in ...
... tract . These items total $ 11,258.32 , for which judgment will be rendered in favor of the plaintiff . It is so ordered . WILLIAMS , Judge ; LITTLETON , Judge ; and WHALEY , Chief Justice , concur . WHITAKER , Judge , took no part in ...
Page 39
... tract , and requested payment thereof . The board duly ap- proved plaintiff's bill and transmitted it to the General Accounting Office for preaudit before payment . The Gen- eral Accounting Office refused to authorize payment of the ...
... tract , and requested payment thereof . The board duly ap- proved plaintiff's bill and transmitted it to the General Accounting Office for preaudit before payment . The Gen- eral Accounting Office refused to authorize payment of the ...
Page 46
... tract " ) , and on May 26 , 1921 , plaintiff and defendant sup- plemented the original contract by a contract ( hereinafter referred to as the " supplement contract " ) . Both these contracts were prepared and drafted by the defendant ...
... tract " ) , and on May 26 , 1921 , plaintiff and defendant sup- plemented the original contract by a contract ( hereinafter referred to as the " supplement contract " ) . Both these contracts were prepared and drafted by the defendant ...
Other editions - View all
Common terms and phrases
additional agreed agreement alleged allowed amended amount appraised approved April Atoka August authority bank barges basis benefit borrow pits building change order Chickasaw nations Chief of Engineers Choctaw and Chickasaw Commissioner completed concrete Congress contract item contracting officer contractor cost cubic yard cut-off trenches decision deduction defendant defendant's delay disbursed entitled to recover expenses extra filed fiscal Five Civilized Tribes follows furnished Goltra Government grout held income tax Indian installation interest Interior January January 14 judgment July June June 22 lands Left Ridge Dam levee liability liquidated damages Madden Dam March March 25 material ment National October Opinion paid paragraph payment performed petition pipes plaintiff purchase purpose pursuant reason reference Reporter's Statement river rock excavation Saddle Dam Secretary Shipping Board sold specifications Stat statute thereof tiffs timber tion towboats tract treaty tribal unit price
Popular passages
Page 80 - To establish and maintain such balance between the production and consumption of agricultural commodities, and such marketing conditions therefor, as will reestablish prices to farmers at a level that will give agricultural commodities a purchasing power with respect to articles that farmers buy, equivalent to the purchasing power of agricultural commodities in the base period.
Page 233 - If the Contractor refuses or fails to prosecute the work, or any separable part thereof, with such diligence as will insure its completion within the time specified in this contract, or any extension thereof, or fails to complete said work within such time, the Government may, by written notice to the Contractor, terminate his right to proceed with the work or such part of the work as to which there has been delay.
Page 258 - May 7, 1925, dismissed the petition on the ground that it fails to state a cause of action.
Page 290 - In the case of an individual, losses sustained during the taxable year and not compensated for by insurance or otherwise — (1) if incurred in trade or business; or (2) if incurred in any transaction entered into for profit, though not connected with the trade or business...
Page 209 - Surety) are held and firmly bound unto the United States of America in the sum of dollars ($ ) for the payment of which sum well and truly to be made, we bind ourselves, our heirs, executors, administrators, successors and assigns, Jointly and severally, firmly by these presents.
Page 279 - CHANGES The Contracting Officer may at any time, by a written order, and without notice to the sureties, make changes, within the general scope of this contract, in any one or more of the following...
Page 234 - ... the Government may. by written notice to the Contractor, terminate his right to proceed with the work or such part of the work as to which there has been delay. In such event the Government may take over the work and prosecute the same...
Page 447 - The President may exercise the power and authority hereby vested in him, and expend the money herein and hereafter appropriated through such agency or agencies as he shall determine from time to time...
Page 143 - ... may be awarded and paid by the Secretary of the Treasury a compensation of 25 per centum of the net amount recovered, but not to exceed $50,000 in any case, which shall be paid out of any appropriations available for the collection of the revenue from customs.
Page 690 - ... shall be paid to every honorably discharged enlisted man of the other grades who reenlists within a period of three months from the date of his discharge.