The Code of Federal Regulations of the United States of AmericaU.S. Government Printing Office, 1982 - Administrative law The Code of Federal Regulations is the codification of the general and permanent rules published in the Federal Register by the executive departments and agencies of the Federal Government. |
From inside the book
Results 1-5 of 80
Page 13
... compensate for changes in ap- plicable Federal excise taxes or duties . It does not provide for any adjustment in the contract price to compensate for changes in State or local taxes ( but see § 1-11.401-4 ( b ) ) . ( c ) Contract ...
... compensate for changes in ap- plicable Federal excise taxes or duties . It does not provide for any adjustment in the contract price to compensate for changes in State or local taxes ( but see § 1-11.401-4 ( b ) ) . ( c ) Contract ...
Page 21
... compensation practices , whether or not they are provided for in labor- management agreements , are not an ... compensated at a premium rate of pay . 21 Chapter 1 - Federal Procurement Regulations § 1-12.102-1.
... compensation practices , whether or not they are provided for in labor- management agreements , are not an ... compensated at a premium rate of pay . 21 Chapter 1 - Federal Procurement Regulations § 1-12.102-1.
Page 22
... compensation paid to an employee at the contrac- tor's regular rate of pay for the base or regular work shift and that paid at the regular rate of pay for extra - pay- shift work . ( d ) " Overtime premium " means the difference between ...
... compensation paid to an employee at the contrac- tor's regular rate of pay for the base or regular work shift and that paid at the regular rate of pay for extra - pay- shift work . ( d ) " Overtime premium " means the difference between ...
Page 25
... compensation at a rate not less than one and one - half times the basic rate of pay for all hours worked in any workweek in excess of 8 hours in any calendar day or in excess of 40 hours in the work- week , as the case may be ...
... compensation at a rate not less than one and one - half times the basic rate of pay for all hours worked in any workweek in excess of 8 hours in any calendar day or in excess of 40 hours in the work- week , as the case may be ...
Page 49
... compensation required under the Act . ( c ) The Act , as amended , and the De- partment of Labor's regulations impose on successor contractors cer- tain requirements with respect to the payment of wages and fringe benefits based on ...
... compensation required under the Act . ( c ) The Act , as amended , and the De- partment of Labor's regulations impose on successor contractors cer- tain requirements with respect to the payment of wages and fringe benefits based on ...
Other editions - View all
Common terms and phrases
activities Administration advance payments allocated allowable amended amount ance applicable appropriate approval Architect-Engineer assets assignment award basis bidder bids certificate charges cluding compensation compliance construction contract price contracting officer contractor Cost Accounting Standards cost objective cost-reimbursement costs incurred Davis-Bacon Act depreciation direct employees Equal Opportunity clause equipment ernment excise tax Executive Order exemption expenses extent facilities Federal agency fringe benefits furnished Government indirect cost inspection institution July 24 lease material ment negotiated offeror organization otherwise paragraph percent performance period prescribed prime contractor prior procedures procurement progress payments proposed purchase purpose pursuant quired reasonable regulations Reinsurance request Secretary of Labor September 24 shipment small business concerns solicitation specific sponsored agreements Standard Form subcon subcontracts submitted Subpart supplies surety term termination tion tract tractor unallowable United wage determination
Popular passages
Page 213 - That any such decision shall be final and conclusive unless the same Is fraudulent or capricious or arbitrary or so grossly erroneous as necessarily to Imply bad faith or Is not supported by substantial evidence. In connection with any appeal proceeding under this clause, the Contractor shall be afforded an opportunity to be heard and to offer evidence In support of his appeal.
Page 36 - ... may be declared ineligible for further government contracts in accordance with procedures authorized in Executive Order No. 11246 of September 24, 1965 and such other sanctions may be imposed and remedies invoked as provided in Executive Order No. 11246 of September 24, 1965, or by rule, regulation, or order of the Secretary of Labor, or as otherwise provided by law. (7) The contractor will include the provisions of Paragraphs (1) through (7) in every subcontract or purchase order unless exempted...
Page 255 - The decision of the Secretary or his duly authorized representative for the determination of such appeals shall be final and conclusive unless determined by a court of competent jurisdiction to have been fraudulent, or capricious, or arbitrary, or so grossly erroneous as necessarily to imply bad faith, or not supported by substantial evidence.
Page 216 - The Contractor warrants that no person or selling agency has been employed or retained to solicit or secure this contract upon an agreement or understanding for a commission, percentage, brokerage, or contingent fee. excepting bona fide employees or bona fide' established commercial or selling agencies maintained by the Contractor for the purpose of securing business. For breach or violation of this warranty the Government shall have the right to annul this contract without liability, or In Its discretion...
Page 216 - The contractor will send to each labor union or representative of workers with which he has a collective bargaining agreement or other contract or understanding, a notice, to be provided by the agency contracting officer, advising the labor union or workers' representative of 'the contractor's commitments under Section 202 of Executive Order No.
Page 213 - Officer grants a further period of time before the date of final payment under the contract), notifies the Contracting Officer in . writing of the causes of delay. The Contracting Officer shall ascertain the facts and the extent of the delay and extend the time for completing the work when, in his judgment, the findings of fact justify such an extension...
Page 193 - The Contractor will take such action with respect to any subcontract or purchase order as the contracting agency may direct as a means of enforcing such provisions, including sanctions for noncompliance : Provided, however, That in the event the Contractor becomes involved in, or is threatened with, litigation with a subcontractor or vendor as a result of such direction by the contracting agency, the Contractor may request the United States to enter into such litigation to protect the interests of...
Page 382 - ... any contractor, subcontractor, or other person in connection with the performance of any contract or other operation deemed by the guaranteeing agency to be necessary to expedite production and deliveries or services under Government contracts for the procurement of materials or the performance of services for the national defense...
Page 34 - The Contractor will not discriminate against any employee or applicant for employment because of race, creed, color, or national origin. The Contractor will take affirmative action to ensure that applicants are employed, and that employees are treated during employment, without regard to their race, creed, color, or national origin. Such action shall include, but not be limited to, the following: employment, upgrading, demotion or transfer; recruitment or recruitment advertising; layoff or termination;...
Page 231 - The Contracting Officer may at any time, by a written order, and without notice to the sureties, make changes, within the general scope of this contract, in any one or more of the following: (i) Drawings, designs, or specifications, where the supplies to be furnished are to be specially manufactured for the Government in accordance therewith; (ii) method of shipment or packing; and (iii) place of delivery.