Code of Federal Regulations: Containing a Codification of Documents of General Applicability and Future Effect as of December 31, 1948, with Ancillaries and IndexDivision of the Federal Register, the National Archives, 1984 - Administrative law |
From inside the book
Results 1-5 of 44
Page 86
... invention described in and covered by a patent of the United States ( i ) embodied in the structure or composition of any arti- cle the delivery of which is accepted by the Government under this contract , or ( ii ) uti- lized in the ...
... invention described in and covered by a patent of the United States ( i ) embodied in the structure or composition of any arti- cle the delivery of which is accepted by the Government under this contract , or ( ii ) uti- lized in the ...
Page 120
... invention described in and cov- ered by a patent of the United States in the performance of this contract or any part hereof or any amendment hereto or any subcontract hereunder ( including any lower- tier subcontract ) . ( End of ...
... invention described in and cov- ered by a patent of the United States in the performance of this contract or any part hereof or any amendment hereto or any subcontract hereunder ( including any lower- tier subcontract ) . ( End of ...
Page 153
... inventions . 12-9.156 Reporting of royalties - anticipat- ed or paid . 12-9.157 Refund of royalties . 12-9.158 ... invention ; and , if his patent is infringed , he is protected by law . He may obtain an injunction restraining the ...
... inventions . 12-9.156 Reporting of royalties - anticipat- ed or paid . 12-9.157 Refund of royalties . 12-9.158 ... invention ; and , if his patent is infringed , he is protected by law . He may obtain an injunction restraining the ...
Page 154
... inventions made under the contract ? ( See FPR 1-9.107-3 ( a ) ( 3 ) . ) Yes -No Explain the answer . 7. Does the contract require that the con- tractor both ( i ) provide services for oper- ation of a Government - owned research or ...
... inventions made under the contract ? ( See FPR 1-9.107-3 ( a ) ( 3 ) . ) Yes -No Explain the answer . 7. Does the contract require that the con- tractor both ( i ) provide services for oper- ation of a Government - owned research or ...
Page 155
... invention described in and covered by a patent of the United States by a con- tractor or by a subcontractor ( includ- ing lower - tier subcontractors ) can be maintained only against the Govern- ment in the Court of Claims and not ...
... invention described in and covered by a patent of the United States by a con- tractor or by a subcontractor ( includ- ing lower - tier subcontractors ) can be maintained only against the Govern- ment in the Court of Claims and not ...
Other editions - View all
Common terms and phrases
accordance Administration advance payment agency agreement amount ance applicable appropriate approval authorized award Background Patent bids Board Buy American Act carrier cation Chapter claims clause set cluding contract clauses Contracting Officer cost Cost accounting standards debarment delivery Department determined DOTPR employees End of clause equipment ernment evaluation Federal FEHBP contracts following clause funds furnished future contract Government property Indian Insert the clause instant contract labor license material ment modification negotiated notice offeror offi OWRT paragraph Patent Rights performance prior procedures procuring activity proposed proprietary data prospective contractor purchase pursuant quired records request Revised royalties schedule Scope of subpart scribed therein Secretary sion small business solicitation Special Bank Account specific subcon subcontract Subject Invention submitted supplies technical data tion tracting officer tractor United Value engineering VECP waiver
Popular passages
Page 301 - In such event, adjustment in the contract price shall be made as provided in paragraph (b) of this clause. (e) The rights and remedies of the Government provided in this clause are in addition to any other rights and remedies provided by law or under this contract. 5. DISPUTES (a) Except as otherwise provided in this contract, any dispute concerning a question of fact arising under this contract which is not disposed of by agreement shall be decided...
Page 305 - Withholding for unpaid wages anil liquidated damages. The Contracting Officer may withhold from the Government Prime Contractor, from any moneys payable on account of work performed by the Contractor or subcontractor, such sums as may administratively be determined to be necessary to satisfy any liabilities of such Contractor or subcontractor for unpaid wages and liquidated damages as provided in the provisions of paragraph ( b ) . (d) Subcontracts.
Page 301 - In connection with any appeal proceeding' under this clause, the Contractor shall be afforded an opportunity to be heard and to offer evidence in support of its appeal. Pending final decision of a dispute hereunder, the Contractor shall proceed diligently with the performance of the contract and in accordance with the Contracting Officer's decision. (b) This "Disputes...
Page 304 - If this contract is completely or partially terminated, the records relating to the work terminated shall be preserved and made available for a period of 3 years from the date of any resulting final settlement. (II) Records which relate to (A) appeals under the "Disputes...
Page 304 - Government under this contract may be assigned to a bank, trust company, or other financing institution, including any Federal lending agency, and may thereafter be further assigned and reassigned to any such institution. Any such assignment or reassignment shall cover all amounts payable under this contract and not already paid, and shall not be made to more than one party, except that any such assignment or reassignment may be made to one party as agent or trustee for two or more parties participating...
Page 52 - ... for technical or special property that he determines to require a substantial initial investment or an extended period of preparation for manufacture, and for which he determines that formal advertising would be likely to result in additional cost to the Government by reason of duplication of investment or would result in duplication of necessary preparation which would unduly delay the procurement of the property...
Page 378 - Data delivered under this contract. (e) Nothing contained in this clause shall imply a license to the Government under any patent or be construed as affecting the scope of any license or other right otherwise granted to the Government under any patent.
Page 356 - Administrator shall prescribe, he may waive all or any part of the rights of the United States under this section with respect to any invention or class of inventions made or which may be made by any person or class of persons in the performance of any work required by any contract of the Administration if the Administrator determines that the interests of the United States will be served thereby.
Page 269 - ... for the particular records specified in Part 1-20 of the Federal Procurement Regulations (41 CFR Part 1-20), whichever expires earlier, have access to and the right to examine any...
Page 142 - ... is being performed. If any inspection, or evaluation is made by the Government on the premises of the Contractor or a subcontractor, the Contractor shall provide and shall require his subcontractors to provide all reasonable facilities and assistance for the safety and convenience of the Government representatives in the performance of their duties. All inspections and evaluations shall be performed in such a manner as will not unduly delay the work.