« PreviousContinue »
power of redelegation. A copy of each (1) The Chief, Procurement and authorized deviation shall be sent to Supply Division, Transportation Systhe Director of Installations and Lo- tems Center, Cambridge, Mass. gistics.
(2) The Chief, Procurement Oper(d) Request for deviations from the ations Division, Washington, D.C. FPR or DOTPR affecting more than (b) In the Federal Aviation Adminisone contract or contractor shall be for- tration: warded to the Director of Installations (1) The Director, Logistics Service, and Logistics. Requests involving devi- Washington, D.C. ations from the FPR will be consid (2) The Director, Metropolitan ered jointly by the Department and Washington Airport Service, Gravelly the General Services Administration, Point, Va. Capital Airports, Falls unless, in the judgment of the Assist
Church, Va. ant Secretary for Administration (3) The Director, Alaskan Region. after due consideration of the objec
Anchorage, Alaska. tive of uniformity and program re- (4) The Director, Western Region. sponsibility of the Department, cir- Los Angeles, Calif. cumstances preclude such joint effort.
(5) The Director, Southern Region, In such cases, the Assistant Secretary
Atlanta, Ga. for Administration will approve such
(6) The Director, Pacific Region, class deviations as he determines nec
Honolulu, Hawaii. essary and will appropriately notify
(7) The Director, Central Region, the General Services Administration.
Kansas City, Mo.
(8) The Director, Eastern Region, § 12-1.010 Interagency
New York, N.Y. Policy Committee.
(9) The Director, Southwest Region,
Fort Worth, Tex. The Director of Installations and Lo
(10) The Director, Aeronautical gistics, OST has been designated the
Center, Oklahoma City, Okla. representative for the Department of
(11) The Director, National Aviation Transporation on the Interagency
Facilities Experimental Center, AtlanProcurement Policy Committee.
tic City, N.J.
(12) The Director, New England Subpart 12-1.2-Definition of Terms Region, Burlington, Mass.
(13) The Director, Great Lakes 8 12–1.204 Head of the agency.
Region, Des Plaines, Ill. “Head of the agency” means the
(14) The Director, Rocky Mountain Secretary and the following assistant
Region, Denver, Colo. chief officials: the Deputy Secretary,
(15) The Director, Northwest the Assistant Secretary for Adminis
Region, Seattle, Wash. tration; and for procurements within
(c) In the Coast Guard, the Comptheir Administrations, the Administra
troller of the Coast Guard, Washingtors of the Federal Aviation Adminis
(d) For the Federal Highway Admintration, Federal Highway Administration, Federal Railroad Administration,
istration, the Associate Administrator Urban Mass Transportation Adminis
for Administration, Washington, D.C. tration, National Highway
(e) For the National Highway Traf
Traffic Safety Administration, St. Lawrence
fic Safety Administration, the AssociSeaway
ate Administrator for Administration, Development Corporation,
Washington, D.C. and the Commandant, U.S. Coast Guard, and the Director, Transporta
(f) For the Federal Railroad Admin
istration, the Associate Administrator tion System Center.
for Administration, Washington, D.C. $ 12–1.206 Head of the procuring activity.
(g) For the St. Lawrence Seaway De
velopment Corporation, the Director, The following officials have been Office of Procurement and Supply, designated as "head of the procuring Massena, N.Y. activity”:
(h) For the Urban Mass Transporta(a) In the Office of the Secretary: tion, the Director, Office of Procure
ment and Third Party Contract Subpart 12-1.3—General Policies Review, Washington, D.C.
8 12-1.302-3 Contracts between the Gov. 8 12-1.250 Administration.
ernment and Government employees or “Administration" means the Federal business concerns substantially owned Aviation Administration, the Federal or controlled by Government employ. Highway Administration, the Federal ees. Railroad Administration, the Urban Unless a higher authority is speciMass Transportation Administration, fied within an Administration, heads the Coast Guard, the St. Lawrence of procuring activities are authorized Seaway Development Corporation, to except individual contracts from and the National Highway Traffic the policy against awarding contracts Safety Administration. The term “Ad to Government employees or business ministration” also includes the Trans concerns substantially owned or conportation Systems Center, and the trolled by Government employees. Office of Administrative Operations of Each such exception shall be evithe Office of the Secretary. The term
denced by a written determination “Administration" as used, for example,
signed by the head of the procuring in the phrase "in accordance with Ad
activity, setting forth the facts in sufministration procedures” would in
ficient detail to demonstrate that the clude the foregoing organizations,
exception is being granted for the
most compelling reasons, and attachunless the paragraph states otherwise.
ing any supporting documentation. A § 12–1.251 Procurement office.
copy of each such determination, with
attachments, shall be forwarded to the "Procurement office" means an
Director of Installations and Logistics, office with a designated contracting
OST. officer with authority to enter into contracts over $10,000 in value.
$ 12–1.305-3. Deviations from Federal
specifications. § 12–1.252 Change order.
(a) Each Administration shall desig"Change order” means a unilateral nate an official to carry out the rewritten order signed by the contract. sponsibilities set forth in FPR 1-1.305ing officer, and issued to a contractor 3. One copy of each such designation pursuant to the Changes clause of the shall be forwarded to the Director of contract.
Installations and Logistics, OST.
(b) Whenever a notification or rec§ 12-1.253 Supplemental agreement.
ommendation for a change in a Feder“Supplemental agreement” means
al Specification is submitted to the
General Services Administration, as any contract modification or contract amendment which is accomplished by
provided in FPR 1-1.305-3(b)(5), an in
formation copy shall be forwarded to mutual action of the parties.
the Director of Installations and Lo$ 12-1.254 Shall.
gistics, OST. Similarly, the Director of
Installations and Logistics shall be ad“Shall” is imperative.
vised any time the General Services
Administration disapproves a devi. § 12–1.255 May.
ation from a Federal Specification. “May” is permissive. However, the words "no person may * * *" mean
8 12-1.305-50 Index to Federal and Dethat no person is required, authorized,
partment of Defense Specifications and or permitted to do the act proscribed.
Standards. The "Index of Federal Specifications and Standards" and the “Department of Defense Index of Specifications and Standards” are issued annually with periodic supplements. These indexes contain general information pertain
ing to their use and the availability of other Government specifications.
8 12-1.306-1 Mandatory use and applica
tion of Federal Standards. Whenever a request for an exception to the use of a Federal Standard is submitted to the General Services Administration, an information copy of the submission and GSA's response shall be forwarded to the Director of Installations and Logistics, OST. 8 12-1.307-5 Limitations on use of "brand
name or equal” purchase description. Purchase descriptions containing the phrase “or equal” shall not be used as a device to grant an advantage to particular manufacturers by favoring one product over other products, or to substantiate a determination that no other manufacturer's products are equal in quality and performance to the products specifically named. Where a proper determination has been made that only one supplier can furnish the required item or items, the procurement will be accomplished by negotiation in accordance with FPR Part 1-3.
actions and other data. Adherence to this policy will require the assembly of either the original or a copy of all documents pertaining to the procurement in a file consisting of one or more folders. It will also require documentation for the record of all understandings, oral agreements, and any other facts or information pertinent to the transaction. It is left to the discretion of the procurement official to determine the manner in which unwritten matters are documented. However, it would be expected, for example, that those of a complex nature would be carefully documented by typewritten "memorandum for the record", while routine data might be recorded by a handwritten notation in the file. Photographs should be employed wherever they will serve to effectively document pertinent contract matters.
(b) Complete documentation will permit ready reconstruction of all stages of the transaction in order to:
(1) Support actions taken by various personnel in the procurement cycle.
(2) Provide information for internal management review and for reviews by the General Accounting Office.
(3) Supply data for use in preparing replies to legitimate inquiries.
(4) Furnish essential facts in the event of litigation.
(c) Small purchase records shall be maintained in accordance with FPR Subpart 1-3.6 and DOTPR Subpart 12-3.6.
8 12-1.315 Use of liquidated damages pro
visions in procurement contracts.
8 12–1.311 Priorities, allocations and allot
ments. The programs of the Coast Guard and certain programs of the Federal Aviation Administration are defenserelated programs to which the priorities and allocations regulations apply. Rateable contracts and purchase orders shall contain the clause set forth in DOTPR 12-7.150-3 and the appropriate DO or DX rating (and the appropriate allotment number if the order calls for authorized controlled materials) in accordance with the pro. visions of DMS (Defense Materials System) Regulation 1 and BDSA Reg. ulation 2. These regulations are avail. able from the Business and Defense Services Administration of the Depart. ment of Commerce. 8 12-1.313 Records of contract actions.
(a) In compliance with the requirements of FPR 1-1.313, each procurement office shall maintain for each procurement exceeding $10,000 a contract file containing a comprehensive record of all pre-award and post-award
8 12-1.315-2 Policy.
(a) Criteria for use. (1) In proposed contracts involving an item where only a portion of the quantity ordered is for immediate programs, and liquidated damages provisions are considered to be necessary, care shall be taken to have the liquidated damages provisions apply only to the urgent quantity.
(2) The use of liquidated damages provisions should never be construed eus relieving procurement officials of the obligation of establishing realistic delivery or performance schedules. Realistic delivery or performance sched
ules should be a prerequisite to the (c) Enforcement. Where liquidated use of liquidated damages.
damages provisions are used, they (3) Liquidated damages provisions shall be strictly enforced. In making generally should not be used:
partial or progress payments, deduc(i) In contracts for supplies or serv tions for damages should be made on ices required for routine administra the basis of the actual number of days tive purposes.
of delay multiplied by the rate. (ii) In contracts for standard com (d) Termination. If the contract is mercial or "shelf items".
terminated, the contractor remains (iii) In any contract where time
liable for liquidated damages that would permit the needs of the Depart
have accrued. Moreover, on a default ment to be met by termination and re
termination, liquidated damages conprocurement if the initial contractor
tinue to accrue even after default, defaults.
until the Department can reasonably (iv) In small purchases.
obtain delivery of the supplies or per(V) In study, experimental, develop
formance of the service. This is in adment, or research contracts, including equipment contracts requiring devel
dition to any other rights of the Govopmental work.
ernment to damages under default (b) Rate of assessment. (1) Contract
provisions for the excess costs of reing officers must assure that the rate
procuring the supplies or services of of liquidated damages stipulated for a
the terminated contract. given contract is a reasonable forecast
(e) Remission. An information copy of the Government's anticipated dam
of each submission to the Comptroller ages. A fixed formula, based on per General of a recommendation for the centage of value, shall not be used to remission of liquidated damages shall establish the rate of damages. The be forwarded to the Director of Instalminimum amount of liquidated dam lations and Logistics, OST. ages should be based on the estimated cost of inspection and superintendence 8 12-1.318 Disputes clause. for each day of delay in completion. In
When a dispute cannot be settled by addition, the following factors are ex
agreement and a decision under the amples of matters to be considered in
Disputes clause is necessary, the conestablishing the rate of damages:
tracting officer shall review the avail(i) The importance of the item in re
able facts pertinent to the dispute lation to the facility or project for before making his final decision. which it is intended.
When there is any doubt as to wheth(ii) The relative importance of the
er the issue in dispute is subject to the item to the facility or project in the
disputes procedure, a decision will be overall program of the Department.
made pursuant to the Disputes clause. (iii) Any rental of facilities necessi
The disputes procedure shall not be tated by the delay in a construction
invoked in cases when a dispute is completion date.
clearly not subject to the procedure. (iv) Cost of additional maintenance required on structures being replaced
The contracting officer shall obtain,
from assigned legal and other advisors, by contract items. (v) Any unusual damages that can be
such advice and assistance as is reanticipated.
quired to render a decision. However, (2) Unless it is clear that partial de
the decision must be that of the conlivery will proportionately reduce the
tracting officer. extent of probable damages, rates shall not be specified to be applicable
8 12-1.318-50 Contracting officer's deci. to individual units of an item, but
sion under the Disputes clause. rather to quantities of an item or to When a final decision of the congroups of items which are required for tracting officer concerns a dispute delivery or completion at the same that is or may be subject to the Distime. Rates should generally be ex. putes clause, the following paragraph pressed in terms of even dollars per shall be added to the paragraph conday of delay.
tained in FPR 1-1.318-1:
The Department of Transportation Con- (b) In cases where the question of tract Appeals Board is the authorized repre entitlement only has been decided by sentative of the Secretary in hearing, con
the Board and the matter of amount sidering, and deciding such appeals. The
has been remanded to the parties for rules of the Department of Transportation Contract Appeals Board are set forth in the
negotiation, if agreement is not Code of Federal Regulations (41 CFR Part reached the appellant will be afforded 12-60 et seq.).
a prompt decision and an opportunity
to appeal on the matter of amount. 8 12-1.318-51 Agreement after appeal is filed.
8 12-1.320 Subcontractor gifts and kickAfter an appeal has been filed, con backs. tracting agencies are encouraged to
Reports of suspected violations and seek agreement as to disposition of the action being taken shall be furnished controversy. However, such efforts to to the Director of Installations and dispose of a controversy shall not be
Logistics, OST. conducted in lieu of formal Board actions or hearings and shall not result 8 12-1.351 Contract number prefixes. in suspension of processing of an
All contracts, exclusive of purchase appeal, except as ordered or authorized by the Department of Transporta
orders, issued by the Department will
be identified by a number or combination Contract Appeals Board.
tion of letters and numbers, in accord§ 12-1.318-52 Payment after appeal is ance with Department Order 4220.1A filed.
(set forth in DOTPR Part 12-99). In the event of an appeal, the
§ 12–1.352 Industrial security. amount determined to be payable in the decision of the contracting officer, (a) Pursuant to Executive Order less any portion previously paid, nor- 10865 (3 CFR, 1959-63 Comp.) an mally should be paid in advance of any agreement between the Department of decision by the Board without prejuDefense and the Department of Transdice to the rights of either party or portation was entered into on June 1, the appeal.
1967, extending regulations prescribed
by the Secretary of Defense under the 812-1.318-53 Implementation of decisions Executive order to apply to protect reof the Contract Appeals Board.
leases of classified information relat(a) It is the policy of the Depart. ing to DOT contracts and releases of ment of Transportation to take other classified information which prompt action to effect payment in ac. DOT has the responsibility for safecordance with any decision of the Con- guarding. The Office of Investigations tract Appeals Board wholly or partial and Security, OST, has been designatly favorable to the appellant. If, how. ed as the Department of Transportaever, an Administration believes such tion liaison for industrial security matdecision is not "appropriate for review ters. The Defense Logistics Agency in court under prevailing statutory will perform all cognizant security and judicial standards”, it may recom- office functions specified in, and will mend that action be taken to seek ju have the authority and responsibilities dicial review of the Board's decision. prescribed by, Department of Defense The recommendation shall be made to Industrial Security Regulations (ISR) the DOT General Counsel who shall (DOD 5220.22R) and Department of determine whether or not judicial Defense Industrial Security Manual review of the Board's decision will be (DOD 5220.22M). sought. In the event that the DOT (b) Any DOT contract or prospective General Counsel determines that judi contract which would require access to cial review will be sought, the matter classified information by the contracshall be referred to the Department of tor or any of his employees in the bid, Justice and the appellant shall be negotiation, award, performance, or promptly advised that payment in ac- termination of the contract, including cordance with the Board's decision clearances required for visit purposes, will not be made.
is considered to be a “classified con