The Code of Federal Regulations of the United States of AmericaU.S. Government Printing Office, 1980 - Administrative law The Code of Federal Regulations is the codification of the general and permanent rules published in the Federal Register by the executive departments and agencies of the Federal Government. |
From inside the book
Results 1-5 of 100
Page 28
... agrees with the recommended appeal action of the contracting offi- cer , it will request in writing that the SBA Associate Administrator for Pro- curement and Management Assist- ance , Washington , D.C. , review the proposed affirmative ...
... agrees with the recommended appeal action of the contracting offi- cer , it will request in writing that the SBA Associate Administrator for Pro- curement and Management Assist- ance , Washington , D.C. , review the proposed affirmative ...
Page 55
... agree- ment shall be modified only by a modi- fication of the basic agreement itself and shall not be modified or supersed- ed by individual contracts entered into under and subject to the terms of such basic agreement . Any provision ...
... agree- ment shall be modified only by a modi- fication of the basic agreement itself and shall not be modified or supersed- ed by individual contracts entered into under and subject to the terms of such basic agreement . Any provision ...
Page 62
... agree to cancellation of the order without cost or liability to either party . If he agrees , the cancella- tion shall be effected by use of Stand- ard Form 30 , as a No - Cost settlement in accordance with § 1-8.209-4 , signed by the ...
... agree to cancellation of the order without cost or liability to either party . If he agrees , the cancella- tion shall be effected by use of Stand- ard Form 30 , as a No - Cost settlement in accordance with § 1-8.209-4 , signed by the ...
Page 92
... agrees to include this clause or one similar thereto in all subcon- tracts issued under the contract . ( d ) Bonds . In the case of contracts for the construction , alteration , or repair of public buildings or public works ...
... agrees to include this clause or one similar thereto in all subcon- tracts issued under the contract . ( d ) Bonds . In the case of contracts for the construction , alteration , or repair of public buildings or public works ...
Page 93
... agrees to accomplish the maximum amount of sub- contracting , as the Contractor determines is consistent with its efficient performance of the contract , with small business concerns , labor surplus area concerns , or minority business ...
... agrees to accomplish the maximum amount of sub- contracting , as the Contractor determines is consistent with its efficient performance of the contract , with small business concerns , labor surplus area concerns , or minority business ...
Other editions - View all
Common terms and phrases
accordance action Administration agency agreement amended amount ance appeal applicable appropriate approval authorized award bidder bills of lading Board Buy American Act cation certificate clause is set clude contracting officer Contractor copy cost curement debarment delivery Department determination DHEW Director documents employees ernment evaluation facilities Federal Supply funds furnished Government property GSA Form GSPR inspection invitation for bids issued June 29 June 30 Labor liquidated damages material ment negotiated notice notify offeror offi Office of Operations option paragraph payment performance period prescribed prior procedures procuring activity proposed purchase order pursuant quantity quired receipt Regulations request responsible Schedule Scope of subpart set-aside sion small business solicitation sources specifications Standard Form subcontract submitted termination thereof tion tracting officer tractor
Popular passages
Page 195 - ... race, creed, color, or national origin. Such action shall Include, but not be limited to, the following: Employment, upgrading, demotion, or transfer; recruitment or recruitment advertising; layoff or termination; rates of pay or other forms of compensation; and selection for training, Including apprenticeship. The Contractor agrees to post in conspicuous places, available to employees and applicants for employment, notices to be provided by the Contracting Officer setting forth the provisions...
Page 107 - Except as otherwise provided in this contract, the term "subcontract" includes purchase orders under this contract. Clause No. 2— Disputes. (a) Except as otherwise provided In this contract, any dispute concerning a question of fact arising under this contract which is not disposed of by agreement shall be decided by the Contracting Officer, who shall reduce his decision to writing and mail or otherwise furnish a copy thereof to the Contractor.
Page 120 - September 24, 1965, so that such provisions will be binding upon each subcontractor or vendor. The contractor will take such action with respect to any subcontract or purchase order as the contracting agency may direct as a means of enforcing such provisions including sanctions for noncompliance; Provided, however, That in the event the contractor becomes involved in or is threatened with, litigation with a subcontractor or vendor as a result of such direction by the contracting agency, the contractor...
Page 127 - The Contractor will furnish all information and reports required by Executive Order No. 11246 of September 24, 1965, and by the rules, regulations, and orders of the Secretary of Labor, or pursuant thereto, and will permit access to his books, records, and accounts by the contracting agency and the Secretary of Labor for purposes of investigation to ascertain compliance with such rules, regulations, and orders.
Page 126 - Clause 17, during the performance of this contract the Contractor agrees as follows: (a) The Contractor will not discriminate against any employee or applicant for employment because of race, creed, color, or national origin. The Contractor will take affirmative action to ensure that applicants are employed, and that employees are treated during employment, without regard to their race, creed, color, or national origin.
Page 190 - Invention or discovery" includes any art, machine, manufacture, design, or composition of matter, or any new and useful improvement thereof, or any variety of plant, which is or may be patentable under the patent laws of the United States of America or any foreign country. (c) "Contractor...
Page 371 - The Contracting Officer shall ascertain the facts and the extent of the delay and extend the time for completing the work when, in his judgment, the findings of fact justify such an extension.
Page 231 - As used in this certification, the term "segregated facilities" means any waiting rooms, work areas, rest rooms and wash rooms, restaurants and other eating areas, time clocks, locker rooms and other storage or dressing areas, parking lots, drinking fountains, recreation or entertainment areas, transportation, and housing facilities provided for employees which are segregated by explicit directive or are in fact segregated on the basis of race, creed, color, or national origin, because of habit,...
Page 111 - ... have access to and the right to examine any directly pertinent books, documents, papers, and records of such subcontractor, involving transactions related to the subcontract. The term "subcontract...
Page 119 - Withholding for Unpaid Wages and Liquidated Damages . The Contracting Officer may withhold from the Government Prime Contractor, from any moneys payable on account of work performed by the Contractor or subcontractor, such sums as may administratively be determined to be necessary to satisfy any liabilities of such Contractor or subcontractor for unpaid wages and liquidated damages as provided in the provisions of paragraph (b) . (d) Subcontracts.