Code of Federal Regulations: Containing a Codification of Documents of General Applicability and Future Effect as of December 31, 1948, with Ancillaries and Index

Front Cover
Division of the Federal Register, the National Archives, 1983 - Administrative law

From inside the book

What people are saying - Write a review

We haven't found any reviews in the usual places.

Contents

Other editions - View all

Common terms and phrases

Popular passages

Page 430 - Except as otherwise provided in this contract, any dispute concerning a question of fact arising under this contract which is not disposed of by agreement shall be decided by the Contracting Officer, who shall reduce his decision to writing and mail or otherwise furnish a copy thereof to the Contractor.
Page 66 - September 24, 1965, so that such provisions will be binding upon each subcontractor or vendor. The contractor will take such action with respect to any subcontract or purchase order as the contracting agency may direct as a means of enforcing such provisions including sanctions for noncompliance; Provided, however, That in the event the contractor becomes involved in or is threatened with, litigation with a subcontractor or vendor as a result of such direction by the contracting agency, the contractor...
Page 431 - Government under this contract may be assigned to a bank, trust company, or other financing institution, including any Federal lending agency, and may thereafter be further assigned and reassigned to any such institution. Any such assignment or reassignment shall cover all amounts payable under this contract and not already paid, and shall not be made to more than one party, except that any such assignment or reassignment may be made to one party as agent or trustee for two or more parties participating...
Page 292 - Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather; but in every case the failure to perform must be beyond the control and without the fault or negligence of the Contractor. If the failure to perform is caused by the default of a subcontractor, and if such default arises out of causes beyond the control of both the Contractor and subcontractor, and without the fault or negligence...
Page 261 - Title to the Government Property shall not be affected by the incorporation or attachment thereof to any property not owned by the Government, nor shall such Government Property, or any part thereof, be or become a fixture or lose its identity as personalty by reason of affixation to any realty.
Page 441 - Any claim by the Contractor for adjustment under this clause must be asserted within 30 days from the date of receipt by the Contractor of the notification of change: Provided, however, That the Contracting Officer, if he decides that the facts justify such action, may receive and act upon any such claim asserted at any time prior to final payment under this contract.
Page 296 - To the point of practical application" means to manufacture in the case of a composition or product, to practice in the case of a process, or to operate in the case of a machine, and under such conditions as to establish that the invention is being worked and that its benefits are reasonably accessible to the public.
Page 558 - Officer grants a further period of time before the date of final payment under the contract), notifies the Contracting Officer in writing of the causes of delay. The Contracting Officer shall ascertain the facts and the extent of the delay and extend the time for completing the work when, in his judgment, the findings of fact justify such an extension, and his findings of fact shall be final and conclusive on the parties, subject only to appeal as provided in the "Disputes
Page 66 - Opportunity clause of this contract or with any of the said rules, regulations, or orders, this contract may be canceled, terminated, or suspended, in whole or in part, and the Contractor may be declared ineligible for further Government contracts in accordance with procedures authorized in Executive Order No.
Page 457 - Government will accept such items and remove them or enter into a storage agreement covering the same; provided that the list submitted shall be subject to...

Bibliographic information