The Code of Federal Regulations of the United States of AmericaU.S. Government Printing Office, 1984 - Administrative law The Code of Federal Regulations is the codification of the general and permanent rules published in the Federal Register by the executive departments and agencies of the Federal Government. |
From inside the book
Page 212
Nothing in this contract , however , shall be construed as making final the decision of any administrative official , representative , or board on a question of law . 7. PAYMENTS TO CONTRACTOR ( a ) The Government will pay the contract ...
Nothing in this contract , however , shall be construed as making final the decision of any administrative official , representative , or board on a question of law . 7. PAYMENTS TO CONTRACTOR ( a ) The Government will pay the contract ...
Page 232
... That nothing in this contract shall be construed as making final the decision of any administrativo oficial , representa : ive , or board on a question of law . Contractor shall not be liable for any excess costs if the failure to ...
... That nothing in this contract shall be construed as making final the decision of any administrativo oficial , representa : ive , or board on a question of law . Contractor shall not be liable for any excess costs if the failure to ...
Page 253
If desired , this order ( or a copy theicon may be used by the Contractor as his invoice , in licu of : separate invoice ... That nothing in this contract shall be construcd as making final the decision or any Administrative Official .
If desired , this order ( or a copy theicon may be used by the Contractor as his invoice , in licu of : separate invoice ... That nothing in this contract shall be construcd as making final the decision or any Administrative Official .
Page 257
Nothing in this contract , however , shall be construed as making final the decision of any administrative official , representative , or board on a question of law . 2. RESPONSIBILITY OF THE ARCHITECT - ENGINEER ( a ) The Architect ...
Nothing in this contract , however , shall be construed as making final the decision of any administrative official , representative , or board on a question of law . 2. RESPONSIBILITY OF THE ARCHITECT - ENGINEER ( a ) The Architect ...
What people are saying - Write a review
We haven't found any reviews in the usual places.
Other editions - View all
Common terms and phrases
acceptance accordance accounting action activities additional Administration advance agency agree agreement allocable allowable amended amount applicable appropriate approval assignment authorized award basis benefits bids certificate changes charges clause compensation completion compliance concerns considered construction contained contracting officer contractor costs Department determination direct effect employees Equal equipment established estimated excess Executive exemption extent facilities Federal fringe furnished Government incurred indirect cost inspection institution interest involved Labor lease less limited listed material means ment necessary negotiated notice operation Opportunity Order organization otherwise paid paragraph performance period person prime prior procedures procurement progress payments proposed purchase pursuant reasonable records regulations request responsible result small business specific Standard Form subcontracts submitted Subpart supplies term termination tion tract United unless wage
Popular passages
Page 234 - The Contractor warrants that no person or selling agency has been employed or retained to solicit or secure this contract upon an agreement or understanding for a commission, percentage, brokerage, or contingent fee, excepting bona fide employees or bona fide established commercial or selling agencies maintained by the Contractor for the purpose of securing business.
Page 233 - The contractor will send to each labor union or representative of workers with which he has a collective bargaining agreement or other contract or understanding, a notice, to be provided by the agency contracting officer, advising the labor union or workers' representative of the contractor's commitments under Section 202 of Executive Order No.
Page 310 - ... established commercial or selling agencies maintained by the Contractor for the purpose of securing business. For breach or violation of this warranty the Government shall have the right to annul this contract without liability or, in its discretion, to deduct from the contract price or consideration, or otherwise recover, the full amount of such commission, percentage, brokerage, or contingent fee.
Page 211 - ... the Government may, by written notice to the contractor, terminate his right to proceed with the work or such part of the work as to which there has been a failure to pay said...
Page 212 - ... bank, trust company, or other financing institution, including any Federal lending agency, and may thereafter be further assigned and reassigned to any such institution. Any such assignment or reassignment shall cover all amounts payable under this contract and not already paid, and shall not be made to more than one party, except that any such assignment or reassignment may be made to one party as agent or trustee for two or more parties participating in such financing.
Page 211 - The delay in the completion of the work arises from unforeseeable causes beyond the control and without the fault or negligence of the Contractor, including but not restricted to, acts of God, acts of the public enemy, acts of the Government in either its sovereign or contractual capacity, acts of another contractor in the performance of a contract with the Government, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, unusually severe weather, or delays of subcontractors...
Page 417 - The rights and remedies of the Government provided in this clause shall not be exclusive and are In addition to any other rights and remedies provided by law or under this contract.
Page 192 - September 24, 1965, so that such provisions will be binding upon each subcontractor or vendor. The contractor will take such action with respect to any subcontract or purchase order as the contracting agency may direct as a means of enforcing such provisions including sanctions for noncompliance; Provided, however, That in the event the contractor becomes involved in or is threatened with, litigation with a subcontractor or vendor as a result of such direction by the contracting agency, the contractor...
Page 232 - Contractor shall not be liable for any excess costs if the failure to perform the contract arises out of causes beyond the control and without the fault or negligence of the Contractor. Such causes may include, but are not restricted to, acts of God or of the public enemy, acts of the...
Page 33 - The Contractor will furnish all information and reports required by Executive Order No. 11246 of September 24. 1965, and by the rules, regulations, and orders of the Secretary of Labor, or pursuant thereto, and will permit access to his books, records, and accounts by the contracting agency and the Secretary of Labor for purposes of Investigation to ascertain compliance with such rules, regulations, and orders.