The Code of Federal Regulations of the United States of AmericaU.S. Government Printing Office, 1983 - Administrative law The Code of Federal Regulations is the codification of the general and permanent rules published in the Federal Register by the executive departments and agencies of the Federal Government. |
Other editions - View all
Common terms and phrases
accordance additional Administration Agency or designee agreement allowable costs amount applicable appropriate approval Article Atomic Energy Act authority award fee Buy American Act classified information clause set compensation contract clauses Contracting Officer Cost Accounting Standards cost-reimbursement cost-type contractors Davis-Bacon Act Department determination DOE-PR employees equipment evaluation extent facilities Federal fixed-price FPMR funds furnished Government Headquarters Heads of Procuring indemnity Insert the clause labor license material modified multiyear negotiation nuclear OFCCP offeror OMB CONTROL operating and on-site organizational conflicts paragraph Patent Counsel Patent Rights clause payment performance period personnel prior procedures Procuring Activity proprietary data purchase pursuant regulations reports request Research and Development Rights in Technical schedule Scope of subpart Senior Procurement Official small business concerns solicitation special nuclear material specific subcontracts subject invention submitted supplies technical data termination Tobacco and Firearms unsolicited proposals waiver
Popular passages
Page 261 - ... shall ascertain the facts and the extent of the delay and extend the time for completing the work when in his Judgment the findings of fact Justify such an extension, and his findings of fact thereon shall be final and conclusive on the parties hereto...
Page 45 - research and development' means (1) theoretical analysis, exploration, or experimentation; or (2) the extension of investigative findings and theories of a scientific or technical nature into practical application for experimental and demonstration purposes, including the experimental production and testing of models, devices, equipment, materials, and processes. "y. The term 'Restricted Data...
Page 277 - Invention or discovery" includes any art, machine, manufacture, design, or composition of matter, or any new and useful improvement thereof, or any variety of plant, which is or may be patentable under the patent laws of the United States of America or any foreign country. (c) "Contractor...
Page 211 - Contractor for adjustment under this clause must be asserted within 30 days from the date of receipt by the Contractor of the notification of change: Provided, however. That the Contracting Officer, if he decides) that the facts justify such action, may receive and act upon any such claim asserted at any time prior to final payment under this contract. Failure to agree to any adjustment shall be a dispute concerning a question of fact within the meaning of the clause of this contract entitled "Disputes.
Page 268 - States without license of the owner thereof or lawful right to use or manufacture the same, the owner's remedy shall be by action against the United States in the Court of Claims for the recovery of his reasonable and entire compensation for such use and...
Page 313 - Data. (e) Nothing contained in this clause shall imply a license to the Government under any patent or be construed as affecting the scope of any license or other right otherwise granted to the Government under any patent.
Page 272 - ... which the Contractor has knowledge. (b) In the event of any claim or suit against the Government on account of any alleged patent or copyright infringement arising out of the performance of this contract or out of the use of any supplies furnished or work or services performed hereunder, the Contractor shall furnish to the Government, when requested by the Contracting Officer, all evidence and information in possession of the Contractor pertaining to such suit or claim. Such evidence and information...
Page 513 - Secretary or his delegate, under any of the following methods: (1) the straight line method, (2) the declining balance method, using a rate not exceeding twice the rate which would have been used had the annual allowance been computed under the method described in paragraph (1).
Page 272 - The provisions of this clause shall be applicable only if the amount of this contract exceeds $I 0.000. (a) The contractor shall report to the Contracting Officer, promptly and in reasonable written detail, each notice or claim of patent or copyright infringement based on the performance of this contract of which the contractor has knowledge.
Page 352 - ... terminated. Severance pay is allowable as a cost only to the extent that it is required by law, employeremployee agreement, or established policy that constitutes in effect an implied agreement on the contractor's part.