The Code of Federal Regulations of the United States of AmericaU.S. Government Printing Office, 1983 - Administrative law The Code of Federal Regulations is the codification of the general and permanent rules published in the Federal Register by the executive departments and agencies of the Federal Government. |
Other editions - View all
Common terms and phrases
A-weighted advance planning air carrier air traffic control aircraft airport development amended by Amdt ance antenna Appendix application approach azimuth appropriate approved authorized back azimuth cluding comply components construction contract contractor determination eligible engine equipment FAA Form facility Federal Airport Act Federal Aviation Act Federal Aviation Administrator Federal Aviation Regulation flight function glide path grant agreement holder hull insurance inspec inspection installation instrument ISMLS issued June 23 land liability limit located mainte maintenance marker beacon meet the requirements ment National nautical miles noise owner paragraph payment perform person pilot certificate pilot school planning agency Policy port prescribed procedures project costs property interest proposed public agency quirements radio record Regulations repair station request risk hull Secretary of Labor specific sponsor or planning standards Stat submit Subpart taxicab taxiway terminate tion Transportation United
Popular passages
Page 106 - Act unless such laborer or mechanic receives compensation at a rate not less than one and one-half times his basic rate of pay...
Page 134 - In the event of any violation of the provisions of paragraph (a), the Contractor and any subcontractor responsible therefor shall be liable to any affected employee for his unpaid wages. In addition, such Contractor and subcontractor shall be liable to the United States for liquidated damages. Such liquidated damages .shall be computed with respect to each individual laborer or...
Page 104 - Act [29 CFR part 3], the full amounts due at time of payment computed at wage rates not less than those contained in the wage determination...
Page 132 - ... and such laborers and mechanics; and the wage determination decision^) shall be posted by the contractor at the site of the work in a prominent place where it (they) can be easily seen by the workers.
Page 278 - ... whenever it appears to the Secretary that such insurance adequate for the needs of the waterborne commerce of the United States cannot be obtained on reasonable terms and conditions from companies authorized to do an insurance business in a State of the United States.
Page 280 - ... all interest accruing after entry of judgment until the company has paid, tendered or deposited in court such part of such judgment as does not exceed the limit of the company's liability thereon...
Page 134 - Withholding for unpaid wages anil liquidated damages. The Contracting Officer may withhold from the Government Prime Contractor, from any moneys payable on account of work performed by the Contractor or subcontractor, such sums as may administratively be determined to be necessary to satisfy any liabilities of such Contractor or subcontractor for unpaid wages and liquidated damages as provided in the provisions of paragraph ( b ) . (d) Subcontracts.
Page 86 - Contractor so much of the accrued payments or advances as may be considered necessary (1) to pay laborers and mechanics employed by the Contractor or any subcontractor on the work the full amount of wages required by the contract, and (2...
Page 106 - Such liquidated damages shall be computed, with respect to each individual laborer or mechanic employed In violation of said paragraph F of this provision, in the sum of $10 for each calendar day on which such employee was required or permitted to work In excess of eight hours or in excess of the standard workweek of forty hours without payment of the overtime wages required и. ist, App. i by said paragraph F of this provision (29 CFR 5.5 (c)(2)).
Page 141 - Applicant, or in the case of any transfer of such property, any transferee, for the period during which the real property or structure is used for a purpose for which the Federal financial assistance is extended or for another purpose involving the provision of similar services or benefits.