Page images
PDF
EPUB

tracts

§ 18-7.460 Short form clauses for costreimbursement type research conwith nonprofit institutions (including educational institutions). Notwithstanding the provision of §§ 187.402, 18-7.403, 18-7.451, and 18-7.452, the clauses set forth or referred to in this paragraph § 18-7.460 shall be used in contracts for basic or applied scientific research at nonprofit institutions of higher education or at nonprofit institutions whose primary purpose is the conduct of scientific research when a short form contract is desired. (See § 181.236 (c) for the definition of nonprofit institution.)

[blocks in formation]
[blocks in formation]

garding patent and copyright infringement.

Insert the clause set forth in § 18-9.105.

[blocks in formation]
[blocks in formation]

§ 18-7.350-6.

[blocks in formation]
[blocks in formation]

Insert § 18-7.451-2.

[blocks in formation]

§ 18-7.103-12.

§ 18-7.460-14 Insert the

§ 18-8.705-50(b). § 18-7.460-15

Insert the

liability to

§ 18-6.104-5,

In accordance with the requirements of § 18-7.402-26, insert either the clause set forth in § 18-7.203-22 or the appropriate clause indicated in § 18-7.402-26. When the clause in § 18-7.203-22 is used, the title "Allowable Cost, Fixed Fee, and Payment" in paragraph (c) shall be changed to read "Allowable Cost and Payment."

§ 18-7.460-6

Examination of records.

Insert the clause set forth in § 187.203-7. Pursuant to procedures approved by the Comptroller General, original documentary evidence in support of costs of the transportation of things will not be required pursuant to paragraph (a) (3) of the "Examination of Records" clause. In the case of contracts which establish separate periods of performance, alternate subparagraph (a) (4), set forth in § 18-7.203-7 (b), may be substituted for the corresponding subparagraph of the clause prescribed in § 18-7.203-7(a).

[blocks in formation]

Termination.

clause set forth in

Buy American Act.

clause set forth in

[blocks in formation]

§ 18-7.461 Additional clauses.

When circumstances justify it, the clauses prescribed in §§ 18-7.402, 18

[blocks in formation]

As used throughout this subpart, the term "facilities contract" means a contract under which Government facilities are provided to a contractor by the Government for use in connection with the performance of a separate contract or contracts for supplies or services. When property other than facilites is provided under a facilities contract, it shall be considered facilities for the purposes of that contract unless otherwise provided in the schedule of the contract. Facilities contracts may take any of the following forms:

(a) Consolidated facilities contracts, which provide for both

(1) The acquisition, construction, and installation of facilities; and

(2) The use, maintenance, accountability, and disposition of facilities;

(b) Facilities acquisition contracts, which provide for the acquisition, construction, and installation of facilities;

or

(c) Facilities use contracts, which provide for the use, maintenance, accountability, and disposition of facilities. § 18-7.702

Required clauses for consolidated facilities contracts. The following clauses shall be inserted in all consolidated facilities contracts. § 18-7.702-1 Definitions.

DEFINITIONS (OCTOBER 1967)

As used throughout this Contract the following terms shall have the meanings set forth below:

(a) The term "Administrator" means the Administrator or Deputy Administrator of the National Aeronautics and Space Administration; and the term "his duly authorized representative" means any person or persons or board (other than the Contracting Officer) authorized to act for the Administrator.

(b) The term "Contracting Officer" means the person executing this contract on behalf of the Government, and any other officer or civilian employee who is a properly designated Contracting Officer; and the term includes, except as otherwise provided in this Contract, the authorized representative of a Contracting Officer acting within the limits of his authority.

(c) Except as otherwise provided in this Contract, the term "Subcontracts" includes purchase orders under this Contract.

(d) The term "NASA” means the National Aeronautics and Space Administration.

(e) "Related Procurement Contract" means a Government contract or subcontract thereunder for furnishing supplies or services of any description, for the performance of which the use of the facilities is or may be authorized.

(f) "Facilities" means, for purposes of this contract, all property provided under this contract.

§ 18-7.702-2 Facilities to be provided. FACILITIES TO BE PROVIDED (OCTOBER 1967) (a) The Contractor, at Government expense and subject to the terms and conditions of this contract, shall acquire, construct, or install the Facilities, and perform the work related thereto, described in the Schedule.

(b) The Government, subject to the terms and conditions of this contract, shall furnish to the Contractor the Facilities identified in the Schedule as Government-furnished Facilities. The Contractor, at Government expense, shall perform such work with respect to these Government-furnished Facilities as may be described in the Schedule.

§ 18-7.702-3 Late delivery, diversion, and substitution.

LATE DELIVERY, DIVERSION, AND SUBSTITUTION (MARCH 1963)

(a) The Government shall not be liable to the Contractor for breach of contract by reason of nondelivery or of any delay in the delivery of the Facilities to be furnished by the Government hereunder.

(b) The Government may, if it is determined by the Contracting Officer to be in the best interest of the Government, divert the Facilities by directing:

(1) Delivery of any or all of the Facilities acquired by or furnished to the Contractor hereunder to locations other than those specified in the Schedule; and

(ii) Assignment, to the Government or to third parties, of purchase orders or subcontracts of the Contractor for any or all of the Facilities hereunder.

The work performed by the Contractor in complying with such directions shall be at Government expense.

(c) The Government may furnish any item of the Facilities, in lieu of the acquisition or construction thereof by the Contractor.

In such event, the work performed by the Contractor in connection with the acquisition or construction of such Facilities, including the cost of terminating purchase orders or subcontracts therefor, shall be at Government expense.

(d) Appropriate equitable adjustment may be made in any related procurement contract of the Contractor which so provides and which is affected by any nondelivery, delay, diversion, or substitution under this clause. § 18-7.702-4 Changes.

CHANGES (MARCH 1963)

(a) The Contractor Officer may at any time, by written order and without notice to the sureties, if any, make changes, within the general scope of this contract, in the Facilities or work described in the Schedule. Work performed by the Contractor in complying with any such order shall be at Government expense. If any such change causes an increase or decrease in the estimated cost of this contract, in the time required for its performance, or otherwise affects any other provision of this contract, an equitable adjustment shall be made in the estimated cost, the completion schedule, or both, and the contract shall be modified in writing accordingly. Any claim by the Contractor for adjustment under this clause must be asserted within thirty (30) days from the date of receipt by the Contractor of the notification of change: Provided, however, That the Contracting Officer, if he decides that the facts justify such action, may receive and act upon any such claim asserted at any time prior to final payment under this contract. Failure to agree to any adjustment shall be a dispute concerning a question of fact within the meaning of the "Disputes" clause of this contract. However, nothing in this clause shall excuse the Contractor from proceeding with the contract as changed.

(b) Appropriate equitable adjustment may be made in any related procurement contract of the Contractor which so provides and which is affected by any such change.

In the foregoing clause, the period of "thirty (30) days" within which any claim for adjustment must be asserted may be varied not to exceed "sixty (60) days."

§ 18-7.702-5 Representations and warranties.

REPRESENTATIONS AND WARRANTIES (MARCH 1963)

(a) The Government makes no warranty, express or implied, regarding the condition of fitness for use of any item of the Facilities. To the extent practicable, the Contractor shall be afforded an opportunity to inspect all items of Facilities that are to be furnished by the Government prior to the shipment of such Facilities to the Contractor. In the event that any item of such Facilities is received by the Contractor in a condition not

suitable for the intended use the Contractor shall, within thirty (30) days after receipt and installation thereof, notify the Contracting Officer of such fact and, as directed by the Contracting Officer and at Government expense, either (i) return such item or otherwise dispose of it, or (ii) effect repairs or modifications.

(b) Appropriate equitable adjustment may be made in any related procurement contract of the Contractor which so provides and which is affected by the return or disposition, or the repair or modification, of any item of Facilities under paragraph (a) above.

[blocks in formation]

INSPECTION (OCTOBER 1967)

(a) The Facilities and work called for by this contract shall be subject to inspection and test by the Government, to the extent practicable at all times and places including the period of manufacture. The Contractor shall provide and maintain an inspection system acceptable to the Government covering the Facilities and work called for by this contract. The Government, through any authorized representative, may inspect such Facilities and work at the plant or plants of the Contractor or any of his subcontractors engaged in the performance of this contract. If any inspection or test is made by the Government on the premises of the Contractor or a subcontractor, the Contractor shall provide and shall require subcontractors to provide all reasonable facilities and assistance for the safety and convenience of the Government inspectors in the performance of their duties. All inspections and tests by the Government shall be performed in such a manner as will not unduly delay the work to be performed by the Contractor under this contract or any related procurement contract.

(b) The Contracting Officer may at any time require the Contractor to remedy by correction or replacement any Facilities or work which are defective or otherwise not in conformity with the requirements of this contract. Except as otherwise provided in paragraph (c) below, such corrections and replacements shall be carried out at Government expense if under the terms of this contract the Facilities or work thus corrected or replaced were initially provided or required to be performed at Government expense.

(c) The Contracting Officer may at any time require the Contractor, without cost to the Government hereunder or under any of its related procurement contracts or subcontracts, to correct or replace any Facilities or work which are defective or otherwise not in conformity with the requirements of this contract, if such defects or failures are due to:

(1) Fraud, lack of good faith, or willful misconduct on the part of any of the Contractor's directors or officers, or on the part of any of his managers, superintendents, or other equivalent representatives who has supervision or direction of

(A) All or substantially all of the Contractor's business;

(B) All or substantially all of the Contractor's operations at any one plant or separate location in which this contract is being performed; or

(C) A separate and complete major industrial operation in connection with the performance of this contract; or

(ii) The conduct of one or more individual employees selected or retained by the Contractor after any of the supervisory personnel described in (1) above has reasonable grounds to believe that any such employee is habitually careless or otherwise unqualified.

(d) Corrected or replaced Facilities or work shall be subject to the provisions of this clause in the same manner and to the same extent as Facilities or work originally completed under this contract.

(e) The Contractor shall make his records of all inspection work available to the Government during the performance of this contract and for such longer periods as may be specified in this contract.

§ 18-7.702-7 Excusable delays.

Insert the clause set forth in § 18-8.708. § 18-7.702-8 Location of the facilities. LOCATION OF THE FACILITIES (MARCH 1963)

The Contractor may use the Facilities at any of the locations specified in the Schedule, and, with the prior written approval of the Contracting Officer, at any other location. In granting this approval, the Contracting Officer may prescribe such terms and conditions as he may deem necessary for the protection of the Government's interest in the Facilities involved. Notwithstanding any inconsistency with the provisions of this contract, such terms and conditions shall prevail.

[blocks in formation]

at Government expense, the Government shall pay the Contractor the cost thereof, determined by the Contracting Officer to be allowable in accordance with (1) Part 15, Subpart 5, of the NASA Procurement Regulation as in effect on the date of this contract and (ii) the terms of this contract.

(b) Except as otherwise specifically provided in this contract, the failure of this contract to provide for reimbursement shall not preclude the Contractor from including, as part of the price or cost under any other Government contract or subcontract, an allocable portion of the costs incurred in the performance of any work, duty, or obligation under this contract which are not reimbursable hereunder.

(c) Once each month (or at more frequent intervals, if approved by the Contracting Officer) the Contractor may submit to an authorized representative of the Contracting Officer, in such form and reasonable detail as such representative may require, an invoice or public voucher supported by a statement of cost incurred by the Contractor in the performance of this contract and claimed to constitute allowable cost.

(d) Promptly after receipt of each invoice or voucher and statement of cost, the Government shall, except as otherwise provided in this contract, subject to the provisions of paragraph (e) below, make payment thereof as approved by the Contracting Officer.

(e) At any time or times prior to final payment under this contract, the Contracting Officer may have the invoices or vouchers and statements of cost audited. Each payment theretofore made shall be subject to reduction for amounts included in the related invoice or voucher which are found by the Contracting Officer, on the basis of such audit, not to constitute allowable cost. Any payment may be reduced for overpayments, or increased for underpayments, on preceding invoices or vouchers.

(f) The Contractor agrees that any refunds, rebates, credits, or other amounts (including any interest thereon) accruing to or received by the Contractor or any assignee under this contract shall be paid by the Contractor to the Government, to the extent that they are properly allocable to costs for which the Contractor has been reimbursed by the Government under this contract. Reasonable expenses incurred by the Contractor for the purpose of securing such refunds, rebates, credits, or other amounts shall be allowable costs hereunder when approved by the Contracting Officer. Prior to final payment under this contract, the Contractor and each assignee under this contract whose assignment is in effect at the time of final payment under this contract shall execute and deliver:

(1) An assignment to the Government, in form and substance satisfactory to the Contracting Officer, of refunds, rebates, credits or other amounts (including any interest thereon) properly allocable to costs for

$ 18-7.702-11

which the Contractor has been reimbursed by the Government under this contract; and (ii) A release discharging the Government, its officers, agents, and employees from all labilities, obligations, and claims arising out of or under this contract, subject only to the following exceptions

(A) Specified claims in stated amounts or in estimated amounts where the amounts are not susceptible of exact statement by the Contractor;

(B) Claims, together with reasonable expenses incidental thereto, based upon liabilities of the Contractor to third parties arising out of the performance of this contract: Provided, That such claims are not known to the Contractor on the date of the execution of the release: And provided further, That the Contractor gives notice of such claims in writing to the Contracting Officer not more than six (6) years after the date of the release or the date of any notice to the Contractor that the Government is prepared to make final payment, whichever is earlier; and

(C) Claims for reimbursement of costs (other than expenses of the Contractor by reason of his indemnification of the Government against patent liability), including reasonable expenses incidental thereto, incurred by the Contractor under the provisions of this contract relating to patents.

(b) In paragraph (f) (ii) (B) of the foregoing clause, the period of years may be increased to correspond with any statutory period of limitation applicable to claims of third parties against the That a correcontractor: Provided,

sponding increase is made in the period for retention of records required in paragraph (a) (4) of the "Examination of Records" clause prescribed by § 18-7.70213.

§ 18-7.702-11

Limitation of cost.

LIMITATION OF COST (AUGUST 1969)

(a) It is estimated that the total cost to the Government for the performance of work under the Schedule of this contract which is provided herein to be at Government expense will not exceed the estimated cost set forth in the Schedule, and the Contractor agrees to use his best efforts to perform such work within such estimated cost. If at any time the Contractor has reason to believe that the costs which he expects to incur in the performance of such work in the next succeeding thirty (30) days, when added to all costs previously incurred, will exceed eighty-five percent (85%) of the estimated cost then set forth in the Schedule, or if at any time the Contractor has reason to believe that the total cost to the Government for the performance of such work will be greater or substantially less than the then estimated cost thereof, the Contractor shall notify the

Contracting Officer in writing to that effect, giving his revised estimate of such total cost for the performance of such work.

to

(b) The Government shall not be obligated to reimburse the Contractor under this contract for costs incurred in excess of the estimated cost set forth in the Schedule, and the Contractor shall not be obligated continue the performance of work under this contract which is provided herein to be at Government expense, or to incur costs therefor, in excess of the estimated cost set forth in the Schedule, unless and until the Contracting Officer shall have notified the Contractor in writing that such estimated cost has been increased and shall have specified in such notice a revised estimated cost which shall thereupon constitute the estimated cost of performing such work. When and to the extent that the estimated cost set forth in the Schedule has been increased, any costs incurred by the Contractor in excess of such estimated cost prior to the increase in estimated cost shall be allowable to the same extent as if such costs had been incurred after such increase in estimated cost.

§ 18-7.702-12

Use and charges.

USE AND CHARGES (OCTOBER 1971) (a) The Contractor may use the Facilities without charge in the performance of:

(1) Prime contracts with the Government without which specifically authorize use charge,

(ii) Subcontract held by the Contractor under Government prime contracts or subcontracts of any tier thereunder if the Contracting Officer having cognizance of the prime contract concerned has authorized use without charge by approving a subcontract specifically authorizing such use or has otherwise authorized such use in writing, and

(iii) Other work with respect to which the Contracting Officer has authorized use without charge in writing.

(b) Subject to the payment of a rental therefor, the Contractor may use all or part of the Facilities in the performance of work other than that specified in paragraph (a) above, as authorized in writing by the Contracting Officer or as specifically provided in the Schedule. Use so authorized shall not be construed to constitute a waiver of any rights the Government may have under this contract to terminate the Contractor's right to use all or any part of the Facilities. The amount of rental to be paid for the right to use the Facilities under this paragraph (b) shall be determined in accordance with the following procedures.

(1) The following bases are or shall be established in writing for the rental computation prescribed in subparagraph (2) below in advance of any use of the Facilities under this paragraph:

(i) The rental rates for the right to use the Facilities shall be those set forth in the Attachment.

(ii) The acquisition cost of the Facilities shall be the total cost to the Government,

« PreviousContinue »