The Code of Federal Regulations of the United States of AmericaU.S. Government Printing Office, 1966 - Administrative law The Code of Federal Regulations is the codification of the general and permanent rules published in the Federal Register by the executive departments and agencies of the Federal Government. |
From inside the book
Results 1-5 of 100
Page 13
... notices of termination , and notices of the exercise of an option . § 1-1.220 Procurement item . " Procurement item " means any per- sonal property or nonpersonal service , including construction , alteration , repair , or installation ...
... notices of termination , and notices of the exercise of an option . § 1-1.220 Procurement item . " Procurement item " means any per- sonal property or nonpersonal service , including construction , alteration , repair , or installation ...
Page 25
... notice of award or acceptance by the Government ( in- cluding notice by receipt of contract document executed by the Government ) . The full period which the Government holds out as being available for contract performance should not be ...
... notice of award or acceptance by the Government ( in- cluding notice by receipt of contract document executed by the Government ) . The full period which the Government holds out as being available for contract performance should not be ...
Page 26
... notice of award will be received by a specified date ( see ( b ) ( 2 ) of this § 1-1.316-4 ) , the notice of award , acceptance of proposal , or other con- tract document executed by the Govern- ment shall be sent by certified mail , re ...
... notice of award will be received by a specified date ( see ( b ) ( 2 ) of this § 1-1.316-4 ) , the notice of award , acceptance of proposal , or other con- tract document executed by the Govern- ment shall be sent by certified mail , re ...
Page 28
... notice of appeal ( in trip- licate ) addressed to the [ Title of the head of the agency ] is mailed or otherwise furnished to the Con- tracting Officer . The notice of appeal , which is to be signed by you as the contractor or by an ...
... notice of appeal ( in trip- licate ) addressed to the [ Title of the head of the agency ] is mailed or otherwise furnished to the Con- tracting Officer . The notice of appeal , which is to be signed by you as the contractor or by an ...
Page 39
... notice of the proposed additional debarment shall be furnished to that concern or individual in accord- ance with § 1-1.604-1 . Except as pre- cluded by statute , a debarment may be removed or the period thereof may be reduced by the ...
... notice of the proposed additional debarment shall be furnished to that concern or individual in accord- ance with § 1-1.604-1 . Except as pre- cluded by statute , a debarment may be removed or the period thereof may be reduced by the ...
Other editions - View all
Common terms and phrases
accordance Administration advance payments agency allocable amended amount applicable appropriate approved authorized award basis bidder bond Buy American Act cerns certificate claim clause set contingent fee contract price contracting officer cost or pricing Davis-Bacon Act default delivery determined employees equipment ernment exceed excess excise tax executive agency extent Federal fixed-price formal advertising furnished inventory schedules invitation for bids invoices jewel bearings labor surplus area liability liquidated liquidated damages mailing manufactured material ment negotiated offeror otherwise paragraph percent performance policies portion pricing data prime contractor procedures procurement progress payments proposals Puerto Rico purchase pursuant quantity quired reasonable receipt regulations request research agreements Scope of subpart set-aside settlement small business concerns specifications Standard Form suant subcon subcontract submitted substantial supplies or services surety thereof tion tracting officer tractor type contracts United
Popular passages
Page 343 - The Contractor will not discriminate against any employee or applicant for employment because of race, creed, color, or national origin. The Contractor will take affirmative action to ensure that applicants are employed, and that employees are treated during employment, without regard to their race, creed, color, or national origin. Such action shall include but not be limited to. the following: employment, upgrading, demotion or transfer; recruitment or recruitment advertising; layoff or termination;...
Page 187 - Except as otherwise provided in this contract, any dispute concerning a question of fact arising under this contract which is not disposed of by agreement shall be decided by the Contracting Officer, who shall reduce his decision to writing and mail or otherwise furnish a copy thereof to the Contractor.
Page 187 - The decision of the Secretary or his duly authorized representative for the determination of such appeals shall be final and conclusive unless determined by a court of competent jurisdiction to have been fraudulent, or capricious, or arbitrary, or so grossly erroneous as necessarily to imply bad faith, or not supported by substantial evidence.
Page 30 - COVENANT AGAINST CONTINGENT FEES The Contractor warrants that no person or selling agency has been employed or retained to solicit or secure this contract upon an agreement or understanding for a commission, percentage, brokerage, or contingent fee...
Page 185 - Contracting Officer" means the person executing this contract on behalf of the Government, and any other officer or civilian employee who is a properly designated Contracting Officer; and the term includes, except as otherwise provided in this contract, the authorized representative of a Contracting Officer acting within the limits of his authority. (c) Except as otherwise provided in this contract, the term "subcontracts" includes purchase orders under this contract.
Page 439 - If the Contractor refuses or fails to prosecute the work, or any separable part thereof, with such diligence as will insure its completion within the time specified in this contract, or any extension thereof, or fails to complete said work within such time, the Government may, by written notice...
Page 439 - ... unknown physical conditions at the site, of an unusual nature, differing materially from those ordinarily encountered and generally recognized as inhering in work of the character provided for in this contract.
Page 185 - Contractor for adjustment under this clause must be asserted within 30 days from the date of receipt by the Contractor of the notification of change: Provided, however, That the Contracting Officer, if he decides that the facts justify such action, may receive and act upon any such claim asserted at any time prior to final payment under this contract. Failure to agree to any adjustment shall be a dispute concerning a question of fact within the meaning of the clause of this contract entitled 'Disputes.
Page 328 - Overtime requirements. No Contractor or subcontractor contracting for any part of the contract work which may require or Involve the employment of laborers or mechanics shall require or permit any laborer or mechanic In any workweek In which he Is employed on such work to work In excess of eight hours In any calendar day or in excess of forty hours In such workweek on work subject to the provisions of the Contract Work Hours Standards Act unless such laborer or mechanic receives compensation at a...
Page 439 - Officer grants a further period of time before the date of final payment under the contract), notifies the Contracting Officer in writing of the causes of delay. The Contracting Officer shall ascertain the facts and the extent of the delay and extend the time for completing the work when, in his judgment, the findings of fact justify such an extension, and his findings of fact shall be final and conclusive on the parties subject only to appeal as provided in the clause of this contract entitled "Disputes.