Competitive Bidding for Construction Contracts with GSA |
From inside the book
Results 1-5 of 46
Page iv
... Final Inspection and Tests 46 Partial Occupancy and Use by the Government 46 Accident and Fire Prevention 46 Non - Compliance with Contract Requirements 47 Samples 48 Shop Drawings , Coordination Drawings , and Schedules . 49 Certified ...
... Final Inspection and Tests 46 Partial Occupancy and Use by the Government 46 Accident and Fire Prevention 46 Non - Compliance with Contract Requirements 47 Samples 48 Shop Drawings , Coordination Drawings , and Schedules . 49 Certified ...
Page v
... Substantial Completion Final Close - Out of a Contract Value Engineering Incentive Clause Appeals and the Disputes Clause Exhibits Index 54 55555 54 55 55 55 55 56 56 58 61 167 EXHIBITS ( In order of reference in text ) Page V.
... Substantial Completion Final Close - Out of a Contract Value Engineering Incentive Clause Appeals and the Disputes Clause Exhibits Index 54 55555 54 55 55 55 55 56 56 58 61 167 EXHIBITS ( In order of reference in text ) Page V.
Page vii
... Final Settlement , GSA Form 2542 118 40 Modification of General Provisions , Standard Form 23 - A 119 41 General Conditions , GSA Form 1139 123 42 Modification of General Conditions , GSA Form 1139 127 43 Labor Standards Provisions ...
... Final Settlement , GSA Form 2542 118 40 Modification of General Provisions , Standard Form 23 - A 119 41 General Conditions , GSA Form 1139 123 42 Modification of General Conditions , GSA Form 1139 127 43 Labor Standards Provisions ...
Page 32
... final notice will be forwarded informing the contractor of the Government's intention to terminate unless within 10 days the contractor shows good cause why the Government should not take such action . The damages under the delay ...
... final notice will be forwarded informing the contractor of the Government's intention to terminate unless within 10 days the contractor shows good cause why the Government should not take such action . The damages under the delay ...
Page 36
... Final Settlement " ( EXHIBIT 39 ) which informs you that a check of a specified amount is forthcoming . The customary practice is to make monthly payments to the contractor for all satisfactory work completed , provided job progress is ...
... Final Settlement " ( EXHIBIT 39 ) which informs you that a check of a specified amount is forthcoming . The customary practice is to make monthly payments to the contractor for all satisfactory work completed , provided job progress is ...
Common terms and phrases
acceptance Accounting Office additional ADMINISTRATION PUBLIC BUILDINGS agency amount appeal applicable apprentices and trainees approval authorized representative award Bid Form bid guarantee bid opening bidder Board Buy American Act certificate clause completion comply Construction Contract contract price contract requirements Contracting Officer Contractor agrees copy Corporate Seal Corporate Cost Accounting Standards cost or pricing Davis-Bacon Act decision delay determination drawings employees Employer Identification equipment equitable adjustment execute EXHIBIT Federal filed furnish Government GSA Form inspection invitation for bids liquidated damages material ment minority business enterprises MOD-1139P January modification Name & Address Name(s paragraph parties payroll performance performance bond pricing data prior proposal Public Buildings Service pursuant receipt request Seal Corporate Seal Secretary of Labor small business concerns specifications Standard Form 23-A statement subcontractors submitted SURETY Telephone Number termination thereof tion Title(s tract U.S. Postal Service unless VECP wage ZIP Code
Popular passages
Page 108 - The Contractor warrants that no person or selling agency has been employed or retained to solicit or secure this contract upon an agreement or understanding for a commission, percentage, brokerage, or contingent fee. excepting bona fide employees or bona fide' established commercial or selling agencies maintained by the Contractor for the purpose of securing business. For breach or violation of this warranty the Government shall have the right to annul this contract without liability, or In Its discretion...
Page 75 - ... any location, under his control, where segregated facilities are maintained. He certifies further that he will not maintain or provide for his employees any segregated facilities at any of his establishments, and that he will not permit his employees to perform their services at any location, under his control, where segregated facilities are maintained.
Page 143 - Contractor and subcontractor shall be liable to the United States for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or...
Page 108 - UTILIZATION OF SMALL BUSINESS CONCERNS (a) It is the policy of the Government as declared by the Congress that a fair proportion of the purchases and contracts for supplies and services for the Government be placed with small business concerns.
Page 166 - Officer shall ascertain the facts and the extent of the delay and extend the time for completing the work when In his judgment...
Page 108 - The Contractor will take such action with respect to any subcontract or purchase order as the contracting agency may direct as a means of enforcing such provisions, including sanctions for noncompliance: Provided, however, That in the event the Contractor becomes involved in, or is threatened with, litigation with a subcontractor or vendor as a result of such direction by the contracting agency, the Contractor may request the United States to enter into such litigation to protect the interests of...
Page 108 - Contractor will furnish all information and reports required by Executive Order No. 11246 of September 24, 1965, and by the rules, regulations, and orders of the Secretary of Labor, or pursuant thereto, and will permit access to his books, records, and accounts by the contracting agency and the Secretary of Labor for purposes of investigation to ascertain compliance with such rules, regulations, and orders.
Page 75 - The certification may be submitted either for each subcontract or for all subcontracts during a period (ie, quarterly, semiannually, or annually) . NOTE: The penalty for making false statements in offers is prescribed in 18 USC 1001 or 15U.SC 714m(a).
Page 122 - The contractor agrees to post in conspicuous places, available to employees and applicants for employment, notices in a form to be prescribed by the Director, provided by or through the contracting officer. Such notices shall state the contractor's obligation under the law to take affirmative action...
Page 83 - America, hereinafter called the Government, represented by the contracting officer executing this contract, and...