The Code of Federal Regulations of the United States of AmericaU.S. Government Printing Office, 1969 - Administrative law The Code of Federal Regulations is the codification of the general and permanent rules published in the Federal Register by the executive departments and agencies of the Federal Government. |
From inside the book
Results 1-5 of 100
Page 44
... tion of the covenant against contingent fees or that there is any stigma attached to the contractor - agent relationship . It does mean , however , that the prospective contractor must fill out the representa- tion in the affirmative ...
... tion of the covenant against contingent fees or that there is any stigma attached to the contractor - agent relationship . It does mean , however , that the prospective contractor must fill out the representa- tion in the affirmative ...
Page 66
... tion , to award the contract to the SBA upon such terms and conditions , consist- ent with these regulations , as may be agreed upon between the SBA and the contracting officer . § 18-1.706 § 18-1.706-1 Set - asides for small business ...
... tion , to award the contract to the SBA upon such terms and conditions , consist- ent with these regulations , as may be agreed upon between the SBA and the contracting officer . § 18-1.706 § 18-1.706-1 Set - asides for small business ...
Page 68
... tion . No further appeal action will be taken by the small business specialist . If an SBA representative is not assigned or available , resolution of disagreements on set - asides between the small business specialist and the ...
... tion . No further appeal action will be taken by the small business specialist . If an SBA representative is not assigned or available , resolution of disagreements on set - asides between the small business specialist and the ...
Page 72
... tion of this procurement , he will perform , or cause to be performed , a substantial propor- tion of the production in areas classified at the time of award , or at the time of perform- ance of the contract , as persistent labor sur ...
... tion of this procurement , he will perform , or cause to be performed , a substantial propor- tion of the production in areas classified at the time of award , or at the time of perform- ance of the contract , as persistent labor sur ...
Page 79
... tion at a unit price no greater than 120 percent of the highest unit price at which an award is made on the non - set - aside portion . Negotiations for the set - aside portion will be conducted with such bidders in the following order ...
... tion at a unit price no greater than 120 percent of the highest unit price at which an award is made on the non - set - aside portion . Negotiations for the set - aside portion will be conducted with such bidders in the following order ...
Other editions - View all
Common terms and phrases
accordance adjustment Administrator agency agree agreement amended amount ance applicable appropriate approval authorized award basis bidder bids or proposals Buy American Act cerns certificate claim clause set cluding compliance construction contract price Contracting Officer Contractor copy cost-reimbursement type curement Davis-Bacon Act delivery determination Director of Procurement equipment ernment estimated cost evaluation exceed Executive Order 11246 extent facilities Federal fixed-price furnished Government Insert the clause invitation for bids Jewel Bearing labor surplus area liability materials ment negotiated offeror otherwise paragraph patent payment performance period prime contractor prior procedures procurement office purchase pursuant quired rates reasonable receipt request for proposals Schedule Scope of subpart Secretary of Labor set forth therein set-aside settlement small business concerns solicitation specific subcon subcontract submitted supplies or services technical thereof tion tracting officer tractor type contracts
Popular passages
Page 310 - The decision of the Secretary or his duly authorized representative for the determination of such appeals shall be final and conclusive unless determined by a court of competent Jurisdiction to have been fraudulent, or capricious, or arbitrary, or so grossly erroneous as necessarily to imply bad faith, or not supported by substantial evidence.
Page 353 - Contractor for adjustment under this clause must be asserted within sixty (60) days from the date of receipt by the Contractor of the notification of change: Provided, however, That the Contracting Officer, If he decides that the facts justify such action, may receive and act upon any such claim asserted at any time prior to final payment under this contract. Failure to agree to any adjustment shall be a dispute concerning a question of fact within the meaning of the clause of this contract entitled...
Page 308 - Where the cost of property made obsolete or excess as a result of a change is included in the Contractor's claim for adjustment, the Contracting Officer shall have the right to prescribe the manner of disposition of such property. Failure to agree to any adjustment shall be a dispute concerning a question of fact within the meaning of the clause of this contract entitled "Disputes.
Page 73 - CONCERNS (JAN. 1958) (a) It Is the policy of the Government as declared by the Congress that a fair proportion of the purchases and contracts for supplies and services for the Government be placed with small business concerns. (b) The Contractor agrees to accomplish the maximum amount of subcontracting to small business concerns that the Contractor finds to be consistent with the efficient performance of this contract. (b) The "Small Business Subcontracting Program...
Page 443 - Any such termination shall be effected by delivery to the contractor of a notice of termination specifying the extent to which performance of work under the contract is terminated, and the date upon which such termination becomes effective.
Page 310 - If any surety upon any bond furnished in connection with this contract becomes unacceptable to the Government, or if any such surety fails to furnish reports as to his financial condition from time to time as requested by the Government, the Contractor shall promptly furnish such additional security as may be required from time to time to protect the interests of the Government and of persons supplying labor or materials in the prosecution of the work contemplated by this contract.
Page 462 - Officer grants a further period of time before the date of final payment under the contract), notifies the Contracting Officer in . writing of the causes of delay. The Contracting Officer shall ascertain the facts and the extent of the delay and extend the time for completing the work when, in his judgment, the findings of fact justify such an extension, and his findings of fact shall be final and conclusive on the parties, subject only to appeal as provided in Clause 6 of these General Provisions.
Page 380 - Government will accept title to such items and remove them or enter into a storage agreement covering the same; provided, that the list submitted shall be subject to verification by the Contracting Officer upon removal of the items, or if the items are stored, within fortyfive (45 ) days from the date of submission of the list, and any necessary adjustment to correct the list as submitted shall be made prior to final settlement. (c) After receipt of a Notice of Termination, the Contractor shall submit...
Page 291 - ... means those articles, materials, and supplies, which are to be acquired under this contract for public use; and (iii) a "domestic source end product" means (A) an unmanufactured end product which has been mined or produced in the United States and (B) an end product manufactured in the United States if the cost of the components thereof which are mined, produced, or manufactured in the United States or Canada exceeds 50 percent of the cost of all its components.
Page 381 - Regulation in effect as of the date of this contract, the Contractor and the Contracting Officer may agree upon the whole or any part of the amount or amounts to be paid to the Contractor by reason of the total or partial termination of work pursuant to this clause. The contract shall be amended accordingly, and the Contractor shall be paid the agreed amount. (e) In the event of the failure of the Contractor and the Contracting Officer to agree in whole or in part, as provided in paragraph (d...