The Code of Federal Regulations of the United States of AmericaU.S. Government Printing Office, 1969 - Administrative law The Code of Federal Regulations is the codification of the general and permanent rules published in the Federal Register by the executive departments and agencies of the Federal Government. |
From inside the book
Results 1-5 of 100
Page 8
... Responsible Prospective Contractors Scope of subpart . Sec . 18-1.804-4 18-1.805 Contract authority . tion . 18 ... responsibility and nonresponsibility . Procedures for determining re- sponsibility contractors . General . of prospective ...
... Responsible Prospective Contractors Scope of subpart . Sec . 18-1.804-4 18-1.805 Contract authority . tion . 18 ... responsibility and nonresponsibility . Procedures for determining re- sponsibility contractors . General . of prospective ...
Page 15
... responsible within that organization for the decision as to the prices being bid or offered herein but that he has been authorized in writing to act as agent for the persons responsible for such decision in certifying that such per ...
... responsible within that organization for the decision as to the prices being bid or offered herein but that he has been authorized in writing to act as agent for the persons responsible for such decision in certifying that such per ...
Page 19
... responsible for ascer- taining whether a group of firms seeking to do business with the Government is a pool . In ... Responsibility of pool member . Where a member of a production pool has submitted a bid or proposal in his own name and ...
... responsible for ascer- taining whether a group of firms seeking to do business with the Government is a pool . In ... Responsibility of pool member . Where a member of a production pool has submitted a bid or proposal in his own name and ...
Page 38
... responsible to the contracting officer for conducting the business aspects of the transaction . The negotiator will ... Responsibility for administration of the sources and management of pro- duction and distribution operations have been ...
... responsible to the contracting officer for conducting the business aspects of the transaction . The negotiator will ... Responsibility for administration of the sources and management of pro- duction and distribution operations have been ...
Page 62
... responsible for developing the NASA small business program , advising the Di- rector of Procurement and other NASA ... responsibility for the Labor Surplus Area Program de- scribed in Subpart 18-1.18 of this chap- ter . When the Director ...
... responsible for developing the NASA small business program , advising the Di- rector of Procurement and other NASA ... responsibility for the Labor Surplus Area Program de- scribed in Subpart 18-1.18 of this chap- ter . When the Director ...
Other editions - View all
Common terms and phrases
accordance adjustment Administrator agency agree agreement amended amount ance applicable appropriate approval authorized award basis bidder bids or proposals Buy American Act cerns certificate claim clause set cluding compliance construction contract price Contracting Officer Contractor copy cost-reimbursement type curement Davis-Bacon Act delivery determination Director of Procurement equipment ernment estimated cost evaluation exceed Executive Order 11246 extent facilities Federal fixed-price furnished Government Insert the clause invitation for bids Jewel Bearing labor surplus area liability materials ment negotiated offeror otherwise paragraph patent payment performance period prime contractor prior procedures procurement office purchase pursuant quired rates reasonable receipt request for proposals Schedule Scope of subpart Secretary of Labor set forth therein set-aside settlement small business concerns solicitation specific subcon subcontract submitted supplies or services technical thereof tion tracting officer tractor type contracts
Popular passages
Page 310 - The decision of the Secretary or his duly authorized representative for the determination of such appeals shall be final and conclusive unless determined by a court of competent Jurisdiction to have been fraudulent, or capricious, or arbitrary, or so grossly erroneous as necessarily to imply bad faith, or not supported by substantial evidence.
Page 353 - Contractor for adjustment under this clause must be asserted within sixty (60) days from the date of receipt by the Contractor of the notification of change: Provided, however, That the Contracting Officer, If he decides that the facts justify such action, may receive and act upon any such claim asserted at any time prior to final payment under this contract. Failure to agree to any adjustment shall be a dispute concerning a question of fact within the meaning of the clause of this contract entitled...
Page 308 - Where the cost of property made obsolete or excess as a result of a change is included in the Contractor's claim for adjustment, the Contracting Officer shall have the right to prescribe the manner of disposition of such property. Failure to agree to any adjustment shall be a dispute concerning a question of fact within the meaning of the clause of this contract entitled "Disputes.
Page 73 - CONCERNS (JAN. 1958) (a) It Is the policy of the Government as declared by the Congress that a fair proportion of the purchases and contracts for supplies and services for the Government be placed with small business concerns. (b) The Contractor agrees to accomplish the maximum amount of subcontracting to small business concerns that the Contractor finds to be consistent with the efficient performance of this contract. (b) The "Small Business Subcontracting Program...
Page 443 - Any such termination shall be effected by delivery to the contractor of a notice of termination specifying the extent to which performance of work under the contract is terminated, and the date upon which such termination becomes effective.
Page 310 - If any surety upon any bond furnished in connection with this contract becomes unacceptable to the Government, or if any such surety fails to furnish reports as to his financial condition from time to time as requested by the Government, the Contractor shall promptly furnish such additional security as may be required from time to time to protect the interests of the Government and of persons supplying labor or materials in the prosecution of the work contemplated by this contract.
Page 462 - Officer grants a further period of time before the date of final payment under the contract), notifies the Contracting Officer in . writing of the causes of delay. The Contracting Officer shall ascertain the facts and the extent of the delay and extend the time for completing the work when, in his judgment, the findings of fact justify such an extension, and his findings of fact shall be final and conclusive on the parties, subject only to appeal as provided in Clause 6 of these General Provisions.
Page 380 - Government will accept title to such items and remove them or enter into a storage agreement covering the same; provided, that the list submitted shall be subject to verification by the Contracting Officer upon removal of the items, or if the items are stored, within fortyfive (45 ) days from the date of submission of the list, and any necessary adjustment to correct the list as submitted shall be made prior to final settlement. (c) After receipt of a Notice of Termination, the Contractor shall submit...
Page 291 - ... means those articles, materials, and supplies, which are to be acquired under this contract for public use; and (iii) a "domestic source end product" means (A) an unmanufactured end product which has been mined or produced in the United States and (B) an end product manufactured in the United States if the cost of the components thereof which are mined, produced, or manufactured in the United States or Canada exceeds 50 percent of the cost of all its components.
Page 381 - Regulation in effect as of the date of this contract, the Contractor and the Contracting Officer may agree upon the whole or any part of the amount or amounts to be paid to the Contractor by reason of the total or partial termination of work pursuant to this clause. The contract shall be amended accordingly, and the Contractor shall be paid the agreed amount. (e) In the event of the failure of the Contractor and the Contracting Officer to agree in whole or in part, as provided in paragraph (d...