Code of Federal Regulations

Front Cover
U.S. General Services Administration, National Archives and Records Service, Office of the Federal Register, 1969 - Administrative law

From inside the book

What people are saying - Write a review

We haven't found any reviews in the usual places.

Contents

Other editions - View all

Common terms and phrases

Popular passages

Page 310 - The decision of the Secretary or his duly authorized representative for the determination of such appeals shall be final and conclusive unless determined by a court of competent Jurisdiction to have been fraudulent, or capricious, or arbitrary, or so grossly erroneous as necessarily to imply bad faith, or not supported by substantial evidence.
Page 353 - Contractor for adjustment under this clause must be asserted within sixty (60) days from the date of receipt by the Contractor of the notification of change: Provided, however, That the Contracting Officer, If he decides that the facts justify such action, may receive and act upon any such claim asserted at any time prior to final payment under this contract. Failure to agree to any adjustment shall be a dispute concerning a question of fact within the meaning of the clause of this contract entitled...
Page 308 - Where the cost of property made obsolete or excess as a result of a change is included in the Contractor's claim for adjustment, the Contracting Officer shall have the right to prescribe the manner of disposition of such property. Failure to agree to any adjustment shall be a dispute concerning a question of fact within the meaning of the clause of this contract entitled "Disputes.
Page 73 - CONCERNS (JAN. 1958) (a) It Is the policy of the Government as declared by the Congress that a fair proportion of the purchases and contracts for supplies and services for the Government be placed with small business concerns. (b) The Contractor agrees to accomplish the maximum amount of subcontracting to small business concerns that the Contractor finds to be consistent with the efficient performance of this contract. (b) The "Small Business Subcontracting Program...
Page 443 - Any such termination shall be effected by delivery to the contractor of a notice of termination specifying the extent to which performance of work under the contract is terminated, and the date upon which such termination becomes effective.
Page 310 - If any surety upon any bond furnished in connection with this contract becomes unacceptable to the Government, or if any such surety fails to furnish reports as to his financial condition from time to time as requested by the Government, the Contractor shall promptly furnish such additional security as may be required from time to time to protect the interests of the Government and of persons supplying labor or materials in the prosecution of the work contemplated by this contract.
Page 462 - Officer grants a further period of time before the date of final payment under the contract), notifies the Contracting Officer in . writing of the causes of delay. The Contracting Officer shall ascertain the facts and the extent of the delay and extend the time for completing the work when, in his judgment, the findings of fact justify such an extension, and his findings of fact shall be final and conclusive on the parties, subject only to appeal as provided in Clause 6 of these General Provisions.
Page 380 - Government will accept title to such items and remove them or enter into a storage agreement covering the same; provided, that the list submitted shall be subject to verification by the Contracting Officer upon removal of the items, or if the items are stored, within fortyfive (45 ) days from the date of submission of the list, and any necessary adjustment to correct the list as submitted shall be made prior to final settlement. (c) After receipt of a Notice of Termination, the Contractor shall submit...
Page 291 - ... means those articles, materials, and supplies, which are to be acquired under this contract for public use; and (iii) a "domestic source end product" means (A) an unmanufactured end product which has been mined or produced in the United States and (B) an end product manufactured in the United States if the cost of the components thereof which are mined, produced, or manufactured in the United States or Canada exceeds 50 percent of the cost of all its components.
Page 381 - Regulation in effect as of the date of this contract, the Contractor and the Contracting Officer may agree upon the whole or any part of the amount or amounts to be paid to the Contractor by reason of the total or partial termination of work pursuant to this clause. The contract shall be amended accordingly, and the Contractor shall be paid the agreed amount. (e) In the event of the failure of the Contractor and the Contracting Officer to agree in whole or in part, as provided in paragraph (d...

Bibliographic information