The Code of Federal Regulations of the United States of America

Front Cover
U.S. Government Printing Office, 1965 - Administrative law
The Code of federal regulations is the codification of the general and permanent rules published in the Federal register by the executive departments and agencies of the federal government.

From inside the book

Other editions - View all

Common terms and phrases

Popular passages

Page 404 - USC 15), if this contract provides for payments aggregating $1,000 or more, claims for moneys due or to become due the Contractor from the Government under this contract may be assigned to a bank, trust company, or other financing institution, Including any Federal lending agency, and may thereafter be further assigned and reassigned to any such Institution. Any such assignment or reassignment shall cover all amounts payable under this contract and not already paid, and shall not be made to more...
Page 335 - Disputes" clause does not preclude consideration of law questions in connection with decisions provided for in paragraph (a) above; provided, that nothing in this contract shall be construed as making final the decision of any administrative official, representative, or board on a question of law.
Page 337 - The Contractor warrants that no person or selling agency has been employed or retained to solicit or secure this contract upon an agreement or understanding for a commission, percentage, brokerage, or contingent fee, excepting bona fide employees or bona fide established commercial or selling agencies maintained by the Contractor for the purpose of securing business. For breach or violation of this warranty the Government shall have the right to annul this contract without liability or in its discretion...
Page 335 - In connection with any appeal proceeding under this clause, the Contractor shall be afforded an opportunity to be heard and to offer evidence in support of its appeal. Pending final decision of a dispute hereunder. the Contractor shall proceed diligently with the performance of the contract and in accordance with the Contracting Officer's decision.
Page 410 - Contractor for adjustment under this clause must be asserted within thirty (30) days from the date of receipt by the Contractor of the notification of change; provided, however, that the Contracting Officer, if he decides that the facts justify such action, may receive and act upon any such claim asserted at any time prior to final payment under this contract. Failure to agree to any adjustment shall be a dispute concerning a question of fact within the meaning of the clause of this contract entitled...
Page 491 - Officer grants a further period of time before the date of final payment under the contract), notifies the Contracting Officer in writing of the causes of delay. The Contracting Officer shall ascertain the facts and the extent of the delay and extend the time for completing the work when, in his Judgment, the findings of fact Justify such an extension...
Page 518 - Invention or discovery" includes any art, machine, manufacture, design, or composition of matter, or any new and useful improvement thereof, or any variety of plant, which is or may be patentable under the patent laws of the United States of America or any foreign country.
Page 402 - ... unknown physical conditions at the site, of an unusual nature, differing materially from those ordinarily encountered and generally recognized as inhering in work of the character provided for in this contract.
Page 491 - Contractor shall not be liable for any excess costs if the failure to perform the contract arises out of causes beyond the control and without the fault or negligence of the Contractor Such causes may include, but are not restricted to, acts of God or of the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather, but in every case the failure to perform must be...
Page 418 - Contractor — (A) shall not be required to extend credit to any purchaser; and (B) may acquire any such property under the conditions prescribed by and at a price or prices approved by the Contracting Officer: And provided further, That the proceeds of any such transfer or disposition shall be applied In reduction of any payments to be made by the Government to the Contractor under this contract or shall otherwise be credited to the price or cost of the work covered by this contract or paid In such...

Bibliographic information