Code of Federal Regulations: Containing a Codification of Documents of General Applicability and Future Effect as of December 31, 1948, with Ancillaries and IndexDivision of the Federal Register, the National Archives, 1973 - Administrative law Special edition of the Federal Register, containing a codification of documents of general applicability and future effect ... with ancillaries. |
From inside the book
Results 1-5 of 99
Page 28
... payment or credit , not required by any contractual or other legal obligation , made to the Government by a contractor or subcontractor either as a payment or as an adjustment under one or more contracts or subcontracts . It may be un ...
... payment or credit , not required by any contractual or other legal obligation , made to the Government by a contractor or subcontractor either as a payment or as an adjustment under one or more contracts or subcontracts . It may be un ...
Page 48
... payments for such other costs as the Contracting Officer otherwise has authority to approve , and does approve in writing . ( d ) The Contractor may draw on the Let- ter of Credit using payment vouchers as fol- lows : ( 1 ) Payment ...
... payments for such other costs as the Contracting Officer otherwise has authority to approve , and does approve in writing . ( d ) The Contractor may draw on the Let- ter of Credit using payment vouchers as fol- lows : ( 1 ) Payment ...
Page 161
... payment of invoices or vouchers ; ( 2 ) The number of days required to process invoices or vouchers from receipt through payment in the normal course of business ; and ( 3 ) The need for prolonged acceptance testing or other unusual ...
... payment of invoices or vouchers ; ( 2 ) The number of days required to process invoices or vouchers from receipt through payment in the normal course of business ; and ( 3 ) The need for prolonged acceptance testing or other unusual ...
Page 162
... payment made with reasonable promptness . ( c ) If a bid offers a prompt payment discount for a period less than that speci- fied in the invitation for bids , the dis- count shall not be considered in the eval- uation of bids . If a bid ...
... payment made with reasonable promptness . ( c ) If a bid offers a prompt payment discount for a period less than that speci- fied in the invitation for bids , the dis- count shall not be considered in the eval- uation of bids . If a bid ...
Page 186
... payments in the amount of $ . are hereby authorized pursuant to 10 U.S.C. 2307. Outstanding payments may at no time exceed the unpaid contract price . Date : Instructions : ( Director of Procurement ) 1. A request for advance payment ...
... payments in the amount of $ . are hereby authorized pursuant to 10 U.S.C. 2307. Outstanding payments may at no time exceed the unpaid contract price . Date : Instructions : ( Director of Procurement ) 1. A request for advance payment ...
Other editions - View all
Common terms and phrases
accordance adjustment Administrator agree agreement amount applicable appropriate approval authorized award bidder billing prices bond Buy American Act cerns certified claim clause set contract price Contracting Officer Contractor cost or pricing curement default delivery determination Director of Procurement ernment estimated cost evaluation extent facilities Federal firm fixed-price furnished Government hereunder incentive insert the clause installation invitation for bids Jewel Bearing July 26 labor surplus area liability materials ment NASA Form NASA Headquarters NASA Procurement negotiated offeror paragraph patent payment performance period pricing data prime contractor prior procedures procurement office purchase pursuant quired reasonable receipt reports request request for proposals Schedule Scope of subpart set forth therein set-aside settlement small business concerns solicitation specific subcon subcontract submitted supplies or services surety target target cost technical thereof tion tracting officer tractor
Popular passages
Page 362 - Contractor for adjustment under this clause must be asserted within sixty (60) days from the date of receipt by the Contractor of the notification of change: Provided, however, That the Contracting Officer, if he decides that the facts justify such action, may receive and act upon any such claim asserted at any time prior to final payment under this contract. Failure to agree to any adjustment shall be a dispute concerning a question of fact within the meaning of the clause of this contract entitled...
Page 417 - Contractor (A) shall not be required to extend credit to any purchaser, and (B) may acquire any such property under the conditions prescribed by and at a price or prices approved by the Contracting Officer: And provided further, That the proceeds of any such transfer or disposition shall be applied in reduction of any payments to be made by the Government to the Contractor under this contract or shall otherwise be credited to the price or cost of...
Page 481 - ... the Government may, by written notice to the contractor, terminate his right to proceed with the work or such part of the work as to which there has been delay. In...
Page 481 - Officer grants a further period of time before the date of final payment under the contract), notifies the Contracting Officer in writing of the causes of delay. The Contracting Officer shall ascertain the facts and the extent of the delay and extend the time for completing the work when, in his Judgment, the findings of fact Justify such an extension, and his findings of fact shall...
Page 332 - Disputes" clause does not preclude consideration of law questions In connection with decisions provided for In paragraph (a) above: Provided, That nothing In this contract shall be construed as making final the decision of any administrative official, representative, or board on a question of law.
Page 418 - Government will accept such items and remove them or enter into a storage agreement covering the same: Provided, That the list submitted shall be subject to verification by the Contracting Officer upon removal of the items, or if the items are stored, within forty-five (45) days from the date of submission of the list, and any necessary adjustment to correct the list as submitted shall be made prior to final settlement. (c) After receipt of a Notice of Termination, the Contractor shall submit to...
Page 419 - ... disputes," from any determination made by the contracting officer under paragraph (c) or (e) above, except that if the contractor has failed to submit his claim within the time provided in paragraph (c) above and has failed to request extension of such time, he shall have no such right of appeal. In any case where the contracting officer has made a determination of the amount due under paragraph (c) or (e) above, the Government shall pay to the contractor the following...
Page 386 - Any claim by the Contractor for adjustment under this clause must be asserted within 30 days from the date of receipt by the Contractor of the notification of change: Provided, however, That the Contracting Officer, if he decides that the facts justify such action, may receive and act upon any such claim asserted at any time prior to final payment under this contract.
Page 403 - In effect as of the date of this contract, the Contractor and the Contracting Officer may agree upon the whole or any part of the amount or amounts to be paid to the Contractor by reason of the total or partial termination of work pursuant to this clause.
Page 467 - If the total of such payments is in excess of the amount finally agreed or determined to be due under this clause, such excess shall be payable by the contractor to the Government upon demand, together with interest computed at the rate of 6 percent per annum, for the period from the date such excess payment is received by the contractor to the date on which such excess is repaid to the Government ; provided, however, that no interest shall be charged with respect to any such excess payment attributable...