Code of Federal Regulations: Containing a Codification of Documents of General Applicability and Future Effect as of December 31, 1948, with Ancillaries and Index

Front Cover
Division of the Federal Register, the National Archives, 1973 - Administrative law

From inside the book

What people are saying - Write a review

We haven't found any reviews in the usual places.

Other editions - View all

Common terms and phrases

Popular passages

Page 362 - Contractor for adjustment under this clause must be asserted within sixty (60) days from the date of receipt by the Contractor of the notification of change: Provided, however, That the Contracting Officer, if he decides that the facts justify such action, may receive and act upon any such claim asserted at any time prior to final payment under this contract. Failure to agree to any adjustment shall be a dispute concerning a question of fact within the meaning of the clause of this contract entitled...
Page 417 - Contractor (A) shall not be required to extend credit to any purchaser, and (B) may acquire any such property under the conditions prescribed by and at a price or prices approved by the Contracting Officer: And provided further, That the proceeds of any such transfer or disposition shall be applied in reduction of any payments to be made by the Government to the Contractor under this contract or shall otherwise be credited to the price or cost of...
Page 481 - ... the Government may, by written notice to the contractor, terminate his right to proceed with the work or such part of the work as to which there has been delay. In...
Page 481 - Officer grants a further period of time before the date of final payment under the contract), notifies the Contracting Officer in writing of the causes of delay. The Contracting Officer shall ascertain the facts and the extent of the delay and extend the time for completing the work when, in his Judgment, the findings of fact Justify such an extension, and his findings of fact shall...
Page 332 - Disputes" clause does not preclude consideration of law questions In connection with decisions provided for In paragraph (a) above: Provided, That nothing In this contract shall be construed as making final the decision of any administrative official, representative, or board on a question of law.
Page 418 - Government will accept such items and remove them or enter into a storage agreement covering the same: Provided, That the list submitted shall be subject to verification by the Contracting Officer upon removal of the items, or if the items are stored, within forty-five (45) days from the date of submission of the list, and any necessary adjustment to correct the list as submitted shall be made prior to final settlement. (c) After receipt of a Notice of Termination, the Contractor shall submit to...
Page 419 - ... disputes," from any determination made by the contracting officer under paragraph (c) or (e) above, except that if the contractor has failed to submit his claim within the time provided in paragraph (c) above and has failed to request extension of such time, he shall have no such right of appeal. In any case where the contracting officer has made a determination of the amount due under paragraph (c) or (e) above, the Government shall pay to the contractor the following...
Page 388 - Any claim by the Contractor for adjustment under this clause must be asserted within 30 days from the date of receipt by the Contractor of the notification of change: Provided, however, That the Contracting Officer, if he decides that the facts justify such action, may receive and act upon any such claim asserted at any time prior to final payment under this contract.
Page 403 - In effect as of the date of this contract, the Contractor and the Contracting Officer may agree upon the whole or any part of the amount or amounts to be paid to the Contractor by reason of the total or partial termination of work pursuant to this clause.
Page 467 - If the total of such payments is in excess of the amount finally agreed or determined to be due under this clause, such excess shall be payable by the contractor to the Government upon demand, together with interest computed at the rate of 6 percent per annum, for the period from the date such excess payment is received by the contractor to the date on which such excess is repaid to the Government ; provided, however, that no interest shall be charged with respect to any such excess payment attributable...

Bibliographic information