« PreviousContinue »
21. Biographical Data (June 1990) (a) The contractor agrees to furnish biographical information to the Contracting Officer on forms (SF 171 and 171As) provided for that purpose.
(b) Emergency locator information. The contractor agrees to provide the following information to the Mission Administrative Officer on arrival in the host country regarding himself herself and dependents:
(1) Contractor's full name, home address, and telephone number including any afterhours emergency number(s).
(2) The name and number of the contract, and whether the individual is the contractor or the contractor's dependent.
(3) The name, address, and home and office telephone number(s) of each individual's next of kin.
(4) Any special instructions pertaining to emergency situations such as power of attorney designees or alternate contact persons.
(4) Waiver of orientation for individual contractor.
(c) Transportation costs and travel allowances not to exceed one round trip from the Contractor's residence to place of orientation and return will be reimbursed, pursuant to Clause 10 of the General Provisions, entitled “Travel and Transportation Expenses," if the orientation is more than 80 kilometers 50 miles from the contractor's residence.
Allowable salary costs during the period of orientation are also reimbursable.
22. U.S. Resident Hire Personal Services
Contractor (June 1990) A contractor meeting the definition of a U.S. Resident Hire PSC contained in Section 12, General Provisions, Clause 1, Definitions, shall be subject to U.S. Federal Income Tax, but shall not be eligible for any fringe benefits (except contributions for FICA, health insurance and life insurance), allowances, or differentials, including but not limited to travel and transportation, medical, orientation, home leave, etc., unless such individual can demonstrate to the satisfaction of the Contracting Officer that he/she has received similar benefits/allowances from their immediately previous employer in the Cooperating Country, or the Mission Director determines that payment of such benefits would be consistent with the Mission's policy and practice and would be in the best interest of the U.S. Government. 23. Orientation and Language Training (July
1993) (a) Except as set forth in paragraph (b)(4) below, the Contractor shall receive a maximum of 2 weeks USAID orientation before travel overseas. The dates of orientation shall be selected by the Contractor and approved by the Contracting Officer from the orientation schedule provided by USAID.
(b) As either set forth in the Contract Schedule, or provided in writing by the Contracting Officer, the following may be authorized taking into consideration specific job requirements, contractor's prior overseas experience, or unusual circumstances, in connection with orientation of individual Contractors:
(1) Modified orientation, (2) Language training,
(3) Orientation for Contractor's dependents at contract expense.
24. Conditions for Contracting Prior to Receipt of Security Clearance (July 1993)
(a) U.S. Resident Hire PSC. The contractor may commence work prior to the completion of the security clearance. However, until such time as clearance is received, the contractor shall have no access to classified or administratively controlled materials. Further, failure to obtain clearance will constitute cause for contract termination in accordance with paragraph (a)(2) of General Provision 16 of this contract.
(b) U.S. PSC-Non-Resident Hire. The contractor may elect to commence travel to post immediately to begin work prior to completion of the security clearance. However, until such time as security clearance is rece he contractor shall:
(1) Have no access to classified or administratively controlled materials;
(2) Be authorized to travel to post himself herself only; and
(3) Be authorized no entitlements other than those normally authorized for short term (less than a year) employees at post. Even if the contract is for one year or more, dependents may not accompany contractor unless at his/her expense, and transportation/storage of household/personal effects and motor vehicle will not be financed by USAID prior to the receipt of the security clearance. Upon receipt of clearance, the Contracting Officer will authorize reimbursement of any such costs borne at contractor's expense prior to clearance provided they are reasonable, allocable and allowable. If appropriate given the length of time re maining, the Contracting Officer will authorize dependent travel and shipment/storage of motor vehicle and effects. Allowances which would not be provided to short term employees will be authorized after clearance is received provided that the contractor is otherwise entitled to such benefits. Failure to obtain the security clearance will constitute cause for contract termination in accordance with paragraph (a)(2) of General Provision 16 of this contract.
25. Medical Evacuation (MEDEVAC) Services
(July 1993) (a) The contractor agrees to obtain medevac service coverage for himself/herself
and his/her authorized dependents while performing personal services abroad. Coverage shall be obtained pursuant to the terms of the contract between USAID and USAID's medevac service provider unless exempted in accordance with paragraph (b).
(b) The following are exempted from the requirements in paragraph (a):
(1) Contractors and their dependents with a health insurance program that includes sufficient medevac coverage as approved by the Contracting Officer.
(2) Contractors and their dependents located at Missions where the Mission Director makes a written determination to waive the requirement for such coverage based on findings that the quality of local medical services or other circumstances obviate the need for such coverage.
(c) Information on the current medevac service provider, including application procedures, is available from the Contracting Officer.
[62 FR 39453, July 23, 1997, as amended at 64 FR 42040, Aug. 3, 1999]
APPENDIX E (RESERVED]
APPENDIX F-USE OF COLLABORATIVE
ASSISTANCE METHOD FOR TITLE XII
1. Introduction This appendix provides a detailed description of the collaborative assistance method of contracting. This is a specialized contracting system which may be used for contracting with educational institutions eligible under, and for activities authorized under, Title XII of the Foreign Assistance Act of 1961, as amended, under the circumstances described in AIDAR 715.613–71.
2. Purpose The collaborative assistance system is designed to:
(a) Increase the joint implementation authority and responsibility of the contractor and the LDC;
(b) Encourage more effective collaboration between all participating parties (USAID, host country, and contractor) at important stages, including the design stage of a technical assistance project.
26. Governing Law (Nov 1996) This contract is established under the procurement authorities of the United States Government and shall be interpreted in accordance with the body of Federal Procure ment Law in the United States. This contract is a complete statement of the duties, compensation, benefits, leave, notice, termination, and the like; therefore, the laws of the country of performance with respect to labor and contract matters shall not apply to either the carrying out of the obligations of the parties or to the interpretation of this agreement.
13. FAR Clauses to be Incorporated in Full Text in Personal Services Contracts.
The following FAR Clauses are always to be used along with the General Provisions. They are required in full text. 1. Covenant Against Contingent Fees 52.203–
5 2. Electronic Funds Transfer Payment Meth
ods 52.232-28 3. Disputes 52.233-1 (Alternate 1) 4. Preference for U.S. Flag Air Carriers
52.247-63 14. FAR Clauses to be Incorporated by Ref. erence in Personal Services Contracts
The following FAR Clauses are to be used along with the General Provisions, and when appropriate, be incorporated in each personal services contract by reference: 1. Anti-Kickback Procedures 52.203-7 2. Limitation on Payments to Influence Cer
tain Federal Transactions 52.203-12 3. Audit and Records-Negotiation 52.215-2 4. Privacy Act Notification 52.224-1 5. Privacy Act 52.224-2 6. Taxes--Foreign Cost Reimbursement Con
tracts 52.229-8 7. Interest 52.232-17 8. Limitation of Cost 52.232–20
3. Policy The collaborative assistance approach represents an alternative method for long-term technical assistance which involves professional collaboration with eligible Title XII institutions and LDC counterparts for a problem-solving type activity to develop new institutional forms and capabilities, to devise operating systems and policies, and to conduct joint research and development-including training. In such an activity, the difficulty in defining, in advance, precise and objectively verifiable contractor inputs and long-term project content as a basis for payment usually requires a flexible approach to project design, contracting, and project implementation. Such flexibility is also essential to the collaborative style which is responsive to LDC desires in problem areas of great complexity and varying uncertainty. Other types of technical assistance, which are usually shorter in term are amenable to more precise definition in advance, or involve closely defined and relatively standardized services, or are otherwise more analogous to commodity resource transfers, may be suitable for other contracting methods, e.g., certain forms of institution building, on-the-job training, resource surveys, etc. The collaborative assistance method is an approved method for providing technical assistance when used in accordance with the circumstances outlined above, and with the guidelines set forth in paragraph 4, below.
4. Implementation Procedures (a) Introduction. This paragraph 4, provides background information, guidelines and procedures to effect the implementation of the policy set forth in paragraph 3 of this appendix.
(b) Conditions and practices. In order for this policy to work effectively even when the proposed activity fits the criteria described under Policy, there must also be:
(1) Acceptance of the notion that the host country, in consultation with the contractor, is in the best position to make tactical, day-to-day decisions on project inputs within agreed-upon limitations and output expectations;
(2) Sufficient trust and respect between the Agency and the contractor to allow this flexible implementation authority;
(3) A direct-hire project monitor with appropriate background to be knowledgeable of progress and to assist in an advisory and facilitative capacity, both during and between periodic reviews. In addition, the following important conditions must be met:
(i) Adequate preproject communication between, and identification of assistance required by, the host government and USAID;
(ii) Full joint planning and improved project design (“Joint” as used herein refers to the primary parties, i.e., the collaborating institutions, as well as the host government and USAID. In some instances, it can also include other donors.);
(iii) Careful contractor selection, i.e., matching of the contractor's technical and managerial capabilities to the anticipated requirements of the overseas activity;
(iv) Establishment of relationships between host country, USAID and contractor staff to include host country leadership, flexible implementation authority, and effective management by the contractor;
(v) Improved joint project evaluation, feedback, and replanning; and
(vi) Simplified administrative procedures and greater reliance on in-country logistical support.
(c) Project Stages and Contractor Involvement. In the long-term technical assistance projects as described above, there are four discrete but sometimes overlapping decision stages which take place—with the principal contractor usually involved in the last three.
(1) Problem analysis and project identification. After the host government has indicated a desire for U.S. collaboration on a particular problem and the USAID field mission has determined that the proposed activ. ity is consistent with its program goals and priorities, considerable effort is usually neoessary to refine further the project purpose and type of assistance required and provide a basis for contractor selection. This is a crucial step and is focused on results sought-on what the prospective contractor is expected to produce in relation to resources to be used and to project purpose. It should result in a clear understanding of what the LDC wants. and an overall plan which includes agreement on specific objectives or outputs, acceptable types of activities and inputs and an initial budget-resulting in project documentation. At this step, USAID makes decisions it cannot delegate on what it will support and at what cost. If needed to supplement its direct-hire expertise, USAID can use outside consultants for analysis and advice but retains the ultimate decision for itself in collaboration with, but independent of, the requesting host government. (Normally, the proposed contractor for project definition and subsequent implementation should not have been involved in the problem analysis and project identification stage as a consultant to either the host country government, host institution, or USAID. If a potential contractor has been so involved, particular care must be taken to prevent actual or apparent organizational conflicts of interest in the procurement that follows. This could require at a minimum, a careful assessment and complete documentation of reasons for selection.)
Normally, there will need to be some mutual interaction between the overall planning stage outlined here and the detailed planning and design work which follows in the next phase. There will usually be some overlap, with preliminary decisions in this stage providing a basis for selection of implementing agents for stage (2) which in turn proceeds through some preliminary planning to guide completion of stage (1) as a basis for long-term contracting
(2) Project definition. At this stage, having selected the implementing agent, the U.S. and LDC organizations which will be collaborating in carrying out the project are encouraged to work out, to their mutual 3satisfaction, the particulars of what to do and how to do it (i.e., detailed project design) within the context of LDC leadership and responsibility and the general agreements and budget reached in stage (1). The emphasis here is on the technical approach to be utilized and the scheduling and management of project inputs. This may involve a shortterm reconnaissance and/or an extensive period of detailed joint planning and feeling out of what is feasible during a preliminary
operating phase of the project, possibly lasting as much as a year or more. This stage recognizes the importance, for the problemsolving or ground breaking types of technical assistance, of involving the U.S. and LDC implementing organizations together as soon as the detailed design work begins. USAID's role here is to facilitate, not direct, the joint planning, assure consistency with prior agreements or concur in changes, affirm that the implementing parties have agreed on a reasonable project design, and prepare or cause to be prepared the documentation required for stage (3), including any amendments that might be required to the project documentation. If and when a decision is made by the host government and USAID to proceed into the operating phase with the same contractor, the U.S. intermediary should be treated as a cooperating partner in the negotiation of the subsequent long-term operating agreement(s) with the host government, host institution and USAID.
(3) Implementation. The results of the approach outlined in the stage above should include, in addition to a better understanding and more meaningful commitment by all parties, the following specific products:
(1) A jointly developed life-of-project design which reflects the commitment of all parties and includes clear statements of purpose, principal outputs, eligible types of activity and expenditure limits, critical assumptions, and major progress indicators;
(ii) A workplan and input schedule for the first two years or at least as long as the expenditure period for the next obligation of project funds;
(iii) Provisions for any administrative support, special services or other inputs by the host country, contractor, and/or USAID; and
(iv) A plan for periodic joint evaluation and review or progress and subsequent workplans, normally annually, with the par ticipation of all parties.
Appropriate elements of these agreements and understandings are now embodied in a contract for project implementation, as described in paragraph (d)(3)(1) of the section on Contracting Implications. This contract allows the U.S. intermediary to apply its judgment, reflecting close collaboration with its LDC colleagues, in adjusting the flow of USAID-financed inputs and in making other operational decisions with a minimum of requirements for prior USAID approvals or contract amendments as long as the contractor stays within the bounds of the approved overall plan and budget. In this phase, USAID will give technical assistance contractors the authority and responsibility for using their specialized expertise to the fullest extent in the scheduling and managing of project inputs.
(4) Monitoring, joint evaluation and replanning. With increased flexibility and responsi
bility for implementation placed with the technical assistance contractor, the host government, and/or institutional collaborator, improved and timely progress reporting and periodic, joint, and structured reviews of results and evolving plans are imperative as a basis for monitoring and evaluating contractor performance, revalidating or adjusting project design, and for determining future funding levels and commitments.
Both the contractor's annual report and the joint review should be structured within the framework of purpose, outputs, performance indicators, etc., originally established in the project indentification phase-as modified by detailed project design--and reflected in the Project Agreement and other pertinent documentation. The field review will normally serve as the occasion for discussing changes in or additions to previously agreed-to workplans as well as proposing changes in purpose, types of activities authorized and budgets which require contract amendment. Obviously, the appropriate host government, host institution, and senior contractor officials should be thoroughly involved in the process, which will have to be adapted to the conditions within specific projects and countries. An important USAID responsibility is to assure that there is appropriate host country participation in developing and improving project plans prior to new obligations of funds. The special requirements and responsibilities of the various parties shall also be reflected in the project agreement and contract terms and in guidelines on the content of annual reports, evaluation procedures, etc.
Standard checking on services actually delivered as a basis for reimbursement will be continued including appropriate audit of expenditures.
(d) Contracting implications. The principal elements of change in present contracting practices, as detailed below, are earlier selection and involvement of the prime contractor, contracting by major stages of project design and operations, minimizing the need for precontract negotiations and contract amendments and USAID approvals, and providing technical assistance contractors with the authority and responsibility needed to manage implementation within the approved program bounds.
(1) Selection. The early involvement of the contractor in the definition stage of a longterm technical assistance project, after USAID decides what it wants to undertake in stage (1), does not alter the Agency's responsibility to select its contractors carefully and in full compliance with appropriate contracting regulations and selection procedures. What is required here is that contractor selection be carried out at an earlier stage than has sometimes been the Agency practice in the past or with other types of contracts and in anticipation that the contractor, assuming adequate performance, will participate in all subsequent phases until final completion.
(2) Contracting stages. In contracting, the initial design stage should be separated from the longer term implementation stage without any USAID commitment to undertake the second until it has exercised its independent judgment based on the product of the first plus any outside expert appraisal it and the host country want to use.
The long-term implementation stage itself may be further subdivided into contract periods which permit time between predetermined events for analysis, determination of new project requirements, and evaluation of performance prior to initiating the next phase by contract amendment/extension. If, for any reason, such an examination does not appear to warrant project continuation, then termination of the project and/or contract would be the next step.
(3) Flerible implementation authority. While good project design will eliminate or dimin ish many operational problems, the very nature of long-term technical assistance requires flexible implementation within agreed purposes, ultimate outputs, types of activity and available financing. With these key variables for USAID management control established, contracts should be written so as to minimize the need for amendments and USAID approval of changes in input particulars. This can be facilitated, both for the USAID, host country, institution, and the contractor by:
(i) Retention of operational plan in contract and removal of workplan. The contract narrative will contain the life-of-the-project Operational Plan, consistent with the project design as developed in stage (2) and reflected in the project documentation (and subsequent amendments thereto). The Operational Plan includes a statement of the purpose to be achieved, the outputs to be produced by the contractor and the types of activities to be undertaken, the more significant indicators of progress, a general de scription of the type of inputs that are authorized and intended to be provided during the life of the project, and the overall budget.
In order to allow adjustments at the implementation level without going through the contract amendment process, the detailed but short-term workplan containing specific descriptions and scheduling of all inputs such as numbers and types of staff, participants, commodities, etc., and specific activities, will not be a part of the contract. It is a working document to be modified in the field when the situation demands. The latest version will be available as a supporting document to justify proposed new obligation levels. Normally, the workplan and derived budget will cover a rolling two year period,
i.e., each year another yearly increment is added after review and approval.
(ii) Budget flexibility. To support this implementation flexibility, contract budget or fiscal controls will be shifted from fixed line items for each input category to program categories, permitting the technical assistance contractor to adjust amounts and timing to achieve previously approved types of activity. This same type of flexibility should apply to any local currency supplied for project operations and/or contractor staff support. While an essential corollary to eliminating the workplan from the contract, this is not a unique procedure under cost reimbursement type contracts when the contractor has demonstrated adequate management capability.
(iii) Negotiation of advance understandings. To permit university and international research center contractors to manage their activities in accordance with their own policies and procedures and thereby sharpen their management responsibility while achieving substantial savings in time and reduced documentation, USAID may negotiate advance understandings with its technical assistance contractors on dollar costs and administrative procedures that would be included by reference in its subsequent contracts. Upon receipt of a request from the contractor that their policies be reviewed and approved for usage in their contract in lieu of the standard terms and conditions, OP/PS/OCC, USAID/W will initiate negotiations of such policies in an expeditious manner. The approved policies will be used in all relevant relations involving the Agency and respective contractors in lieu of traditional contract standard provisions, whenever this may be appropriate. This does not apply to local currency costs and host government procedures which must be negotiated in each case.
The purpose of the practices listed above is not only to give a qualified contractor the authority to adjust the composition and timing of inputs but to assign to it clear responsibility for managing such resources, as the evolving circumstances require, to achieve the agreed-upon outputs on a cost efficient basis. It should also reduce the delay and paperwork involved in frequent but minor contract amendments, and approvals. For the agency as a whole, both in the Mission and in USAID/W, these have involved a large workload and cost.
(e) Role of USAID. Nothing in this appendix is intended to delegate, diminish or otherwise modify USAID's final responsibility for the prudent management of public funds and its own programs. Rather in withdrawing from the day-to-day involvement in and responsibility for the management of adjustment of the flow of inputs during the implementation, the best use of limited agency staff and time can be devoted to protecting