Code of Federal Regulations: Containing a Codification of Documents of General Applicability and Future Effect as of December 31, 1948, with Ancillaries and Index

Front Cover
Division of the Federal Register, the National Archives, 1972 - Administrative law

From inside the book

Contents

Other editions - View all

Common terms and phrases

Popular passages

Page 414 - The Contractor warrants that no person or selling agency has been employed or retained to solicit or secure this contract upon an agreement or understanding for a commission, percentage, brokerage, or contingent fee. excepting bona fide employees or bona fide' established commercial or selling agencies maintained by the Contractor for the purpose of securing business. For breach or violation of this warranty the Government shall have the right to annul this contract without liability, or In Its discretion...
Page 374 - Jurisdiction to have been fraudulent, or capricious, or arbitrary, or so grossly erroneous as necessarily to Imply bad faith, or not supported by substantial evidence. In connection with any appeal proceeding under this clause, the Contractor shall be afforded an opportunity to be heard and to offer evidence in support of Its appeal. Pending final decision of a dispute hereunder, the Contractor shall proceed diligently with the performance of the contract and In accordance with the Contracting Officer's...
Page 257 - The contractor will not discriminate against any employee or applicant for employment because of race, creed, color, or national origin. The contractor will take affirmative action to ensure that applicants are employed, and that employees are treated during employment, without regard to their race, creed, color, or national origin.
Page 198 - Officer grants a further period of time before the date of final payment under the contract), notifies the Contracting Officer in writing of the causes of delay. The Contracting Officer shall ascertain the facts and the extent of the delay and extend the time for completing the work when, in his judgment, the findings of fact justify such an extension, and his findings of fact shall be final and conclusive on the parties subject only to appeal as provided in the clause of this contract entitled "Disputes.
Page 257 - Contractor may be declared Ineligible for further Government contracts in accordance with procedures authorized In Executive Order No. 11246 of September 24, 1965, and such other sanctions may be Imposed and remedies Invoked as provided In Executive Order No. 11246 of September 24, 1965, or by rule, regulation, or order of the Secretary of Labor, or as otherwise provided by law. (g) The Contractor...
Page 188 - Officer may direct; (8) complete performance of such part of the work as shall not have been terminated by the Notice of Termination; and (9) take such action as may be necessary, or as the Contracting Officer may direct, for the protection and preservation of the property related to this contract which is in the possession of the Contractor and in which the Government has or may acquire an interest.
Page 374 - ... or (iii) of this clause shall be treated as components mined, produced, or manufactured in the United States. (b) The Contractor agrees that there will be delivered under this contract only domestic source end products, except end products: (i) Which are for use outside the United States; (ii) Which the Government determines are not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities and of a satisfactory quality; (iii) As to which...
Page 192 - If the total of such payments is in excess of the amount finally agreed or determined to be due under this clause, such excess shall be payable by the Contractor to the Government upon demand, together with Interest computed at the rate of 6 percent per annum for the period from the date such excess payment is received by the Contractor to the date on which such excess is repaid to the Government: Provided, however, That no Interest shall be charged with respect to any such excess payment attributable...
Page 188 - ... to be paid to the Contractor in connection with the termination of work pursuant to this clause, the Contracting Officer shall, subject to any review required by the contracting agency's procedures In effect as of the date of execution of this contract, determine, on the basis of information available to him, the amount. If any, due to the Contractor by reason of the termination and shall pay to the Contractor the amount determined as follows...
Page 187 - Contractor — (A) shall not be required to extend credit to any purchaser, and (B) may acquire any such property under the conditions prescribed by and at a price or prices approved by the Contracting Officer; and provided further that the proceeds of any such transfer or disposition shall be applied in reduction of any payments to be made by the Government to the Contractor under this contract or shall otherwise be credited to the price or cost of...

Bibliographic information