The Code of Federal Regulations of the United States of AmericaU.S. Government Printing Office, 1963 - Administrative law The Code of Federal Regulations is the codification of the general and permanent rules published in the Federal Register by the executive departments and agencies of the Federal Government. |
From inside the book
Results 1-5 of 100
Page 18
... Clause . NOTE : In construction contracts insert the phrase " the Termination for Default - Dam- ages for Delay - Time Extension Clause " in lieu of , " paragraph f . of the Default Clause . " ( 3 ) The liquidated damages provision will ...
... Clause . NOTE : In construction contracts insert the phrase " the Termination for Default - Dam- ages for Delay - Time Extension Clause " in lieu of , " paragraph f . of the Default Clause . " ( 3 ) The liquidated damages provision will ...
Page 21
... clause . ( Date of findings and decision ) Subject : Decision Disallowing ... insert factual description of the request to identify clearly its nature and ... ( Insert the findings of fact upon which the disallowance is based . ) 3 ...
... clause . ( Date of findings and decision ) Subject : Decision Disallowing ... insert factual description of the request to identify clearly its nature and ... ( Insert the findings of fact upon which the disallowance is based . ) 3 ...
Page 22
... Clause ( insert the title of the perti- nent termination clause ) of the contract , the undersigned contracting officer finds as fol- lows : ( Insert all pertinent factual data , such as , date of termination of contract , date of ...
... Clause ( insert the title of the perti- nent termination clause ) of the contract , the undersigned contracting officer finds as fol- lows : ( Insert all pertinent factual data , such as , date of termination of contract , date of ...
Page 71
... ( insert amount of delegated contracting authority of con- tracting officer issuing the invitation for bids ) awarded as a result of this invitation shall contain the following approval clause : This contract shall be subject to the ...
... ( insert amount of delegated contracting authority of con- tracting officer issuing the invitation for bids ) awarded as a result of this invitation shall contain the following approval clause : This contract shall be subject to the ...
Page 98
... add the clause in § 1007.4205-27 of this subchapter . ( 3 ) Limitations . Requirements con- tracts will be used only ... enter into a contract with any other contractor for delivery of specified supplies or services during the ...
... add the clause in § 1007.4205-27 of this subchapter . ( 3 ) Limitations . Requirements con- tracts will be used only ... enter into a contract with any other contractor for delivery of specified supplies or services during the ...
Other editions - View all
Common terms and phrases
according administrative contracting officer AFLC AFPI Form AFSC agree agreement Air Force amended at 27 amount applicable appropriate approval ARDC assigned authority award bailment bidder bill of lading Buy American Act certificate chapter clause set Commander Contractor copy cost curement DD Form determination Director of Procurement duction equipment ernment estimated facilities contract following clause funds furnished Government property hereunder Hq AMC Hq USAF Insert the clause inspection instructions issued labor lease lessee letter contract materials MCPP ment negotiated paragraph Patent payment performance personnel prime contractor prior procedures procurement activities proposed purchase pursuant quired rates receipt reimbursement request responsible Schedule III Scope of subpart shipment small business specific staff judge advocate subchapter subcontract submitted termination thereof tion tracting officer tractor United voucher
Popular passages
Page 266 - In connection with any appeal proceeding under this clause, the Contractor shall be afforded an opportunity to be heard and to offer evidence in support of its appeal. Pending final decision of a dispute hereunder, the Contractor shall proceed diligently with the performance of the contract and in accordance with the Contracting Officer's decision. b. This "Disputes...
Page 266 - Except as otherwise provided in this contract, any dispute concerning a question of fact arising under this contract which is not disposed of by agreement shall be decided by the Contracting Officer, who shall reduce his decision to writing and mail or otherwise furnish a copy thereof to the Contractor. The decision of the Contracting Officer shall be final and conclusive unless, within 30 days from the date of receipt of such copy, the Contractor mails or otherwise furnishes to the Contracting Officer...
Page 269 - The Contractor shall promptly, and before such conditions are disturbed, notify the Contracting Officer in writing of: (1) subsurface or latent physical conditions at the site differing materially from those indicated in this contract, or (2) unknown physical conditions at the site...
Page 133 - States, or if articles, materials, or supplies of the class or kind to be used or the articles, materials, or supplies from which they are manufactured are not mined, produced, or manufactured, as the case may be, in the United States in sufficient and reasonably available commercial quantities and of a satisfactory quality.
Page 211 - The Contractor warrants that no person or selling agency has been employed or retained to solicit or secure this contract upon an agreement or understanding for a commission, percentage, brokerage, or contingent fee. excepting bona fide employees or bona fide' established commercial or selling agencies maintained by the Contractor for the purpose of securing business. For breach or violation of this warranty the Government shall have the right to annul this contract without liability, or In Its discretion...
Page 171 - Government in accordance with this clause in whole, or from time to time in part, whenever the contracting officer shall determine that such termination is in the best interest of the Government. Any such termination shall be effected by delivery to the contractor of a notice of termination specifying the extent to which performance of work under the contract is terminated, and the date upon which such termination becomes effective.
Page 214 - ... the Government may, by written notice to the contractor, terminate his right to proceed with the work or such part of the work as to which there has been a failure to pay...
Page 342 - ... contract whenever in the opinion of the contracting officer the aggregate of such payments shall be within the amount to which the contractor will be entitled hereunder. If the total of such payments is in excess of the amount finally agreed...
Page 190 - The performance of work under this contract may be terminated by the Government in accordance with this clause in whole, or from time to time in part, whenever the Contracting Officer shall determine that such termination is in the best interests of the Government.
Page 192 - Government upon demand, together with interest computed at the rate of 6 percent per annum, for the period from the date such excess payment is received by the contractor to the date on which such excess is repaid to the Government ; provided, however, that no interest shall be charged with respect to any such excess payment attributable to a reduction in the contractor's claim by reason of retention or other disposition of termination inventory until...