CONTRACT CLAUSES AND SOLICITATION PROVISIONS The Contractor shall proceed immediately with the performance of the above obligations notwithstanding any delay in determining or adjusting the amount of the fee, or any item of reimbursable cost, under this clause. At any time after expiration of the plant clearance period, as defined in Section VIII, Armed Services Procurement Regulation, as it may be amended from time to time, the Contractor may submit to the Contracting Officer a list, certified as to quantity and quality, of any or all items of termination inventory not previously disposed of, exclusive of items the disposition of which has been directed or authorized by the Contracting Officer, and may request the Government to remove such items or enter into a storage agreement covering them. Not later than fifteen (15) days thereafter, the Government will accept such items and remove them or enter into a storage agreement covering the same; provided, that the list submitted shall be subject to verification by the Contracting Officer upon removal of the items, or if the items are stored, within forty-five (45) days from the date of submission of the list, and any necessary adjustment to correct the list as submitted shall be made prior to final settlement. (c) After receipt of a Notice of Termination, the Contractor shall submit to the Contracting Officer his termination claim in the form and with the certification prescribed by the Contracting Officer. Such claim shall be submitted promptly but in no event later than one year from the effective date of termination, unless one or more extensions in writing are granted by the Contracting Officer, upon request of the Contractor made in writing within such one year period or authorized extension thereof. However, if the Contracting Officer determines that the facts justify such action, he may receive and act upon any such termination claim at any time after such one year period or any extension thereof. Upon failure of the Contractor to submit his termination claim within the time allowed, the Contracting Officer may determine, on the basis of information available to him, the amount, if any, due to the Contractor by reason of the termination and shall thereupon pay to the Contractor the amount so determined. (d) Subject to the provisions of paragraph (c), the Contractor and the Contracting Officer may agree upon the whole or any part of the amount or amounts to be paid (including an allowance for the fee) to the Contractor by reason of the total or partial termination of work pursuant to this clause. The contract shall be amended accordingly, and the Contractor shall be paid the agreed amount. (e) In the event of the failure of the Contractor and the Contracting Officer to agree in whole or in part, as provided in paragraph (d), as to the amounts with respect to costs and fee, or as to the amount of the fee, to be paid to the Contractor in connection with the termination of work pursuant to this clause, the Contracting Officer shall determine, on the basis of information available to him, the amount, if any, due to the Contractor by reason of the termination and shall pay to the Contractor the amount determined as follows: (i) if the settlement includes cost and fee: (A) there shall be included therein all costs and expenses reimbursable in accordance with this contract, not previously paid to the Contractor for the performance of this contract prior to the effective date of the Notice of Termination, and such of these costs as may continue for a reasonable time thereafter with the approval of or as directed by the Contracting Officer; provided, however, that the Contractor shall proceed as rapidly as practicable to discontinue such costs; (B) there shall be included therein so far as not included under (A) above, the cost of settling and paying claims arising out of the termination of work under subcontracts or orders, as provided in paragraph (b)(v) above, which are properly chargeable to the terminated portion of the contract; (C) there shall be included therein the reasonable costs of settlement, including accounting, legal, clerical, and other expenses reasonably necessary for the preparation of settlement claims and supporting data with respect to the terminated portion of the contract and for the termination and settlement of subcontracts, thereunder, together with reasonable storage, transportation, and other costs incurred in connection with the protection or disposition of termination inventory; provided, however, that if the termination is for default of the Contractor there shall not be included any amounts for the preparation of the Contractor's settlement proposal; and (D) there shall be included therein a portion of the fee payable under the contract determined as follows: 7-203.10 ARMED SERVICES PROCUREMENT REGULATION CONTRACT CLAUSES AND SOLICITATION PROVISIONS (I) in the event of the termination of this contract for the convenience of the Government and not for the default of the Contractor, there shall be paid a percentage of the fee equivalent to the percentage of the completion of work contemplated by the contract, but exclusive of subcontract effort included in subcontractors' termination claims, less fee payments previously made hereunder; or (II) in the event of the termination of this contract for the default of the Contractor, the total fee payable shall be such proportionate part of the fee (or, if this contract calls for articles or services of different types, of such part of the fee as is reasonably allocable to the type of article or services under consideration) as the total number of articles or amount of services delivered to and accepted by the Government bears to the total number of articles or amount of services of a like kind called for by this contract; if the amount determined under this subparagraph (i) is less than the total payment theretofore made to the Contractor, the Contractor shall repay to the Government the excess amount; or (ii) if the settlement includes only the fee, the amount thereof will be determined in accordance with the subparagraph (i)(D) above. (f) Costs claimed, agreed to, or determined pursuant to (c), (d), and (e) hereof shall be in accordance with the Section XV Contract Cost Principles and Procedures of the Armed Services Procurement Regulation as in effect on the date of this contract. (g) The Contractor shall have the right of appeal, under the clause of this contract entitled "Disputes", from any determination made by the Contracting Officer under paragraphs (c) or (e) above, except that if the Contractor has failed to submit his claim within the time provided in paragraph (c) above and has failed to request extension of such time, he shall have no such right of appeal. In any case where the Contracting Officer has made a determination of the amount due under paragraph (c) or (e) above, the Government shall pay to the Contractor the following: (i) if there is no right of appeal hereunder or if no timely appeal has been taken, the amount so determined by the Contracting Officer, or (ii) if an appeal has been taken, the amount finally determined on such appeal. (h) In arriving at the amount due the Contractor under this clause, there shall be deducted (i) all unliquidated advance or other payments theretofore made to the Contractor, applicable to the terminated portion of this contract; (ii) any claim which the Government may have against the Contractor in connection with this contract; and (iii) the agreed price for, or the proceeds of sale of, any materials, supplies, or other things acquired by the Contractor or sold pursuant to the provisions of the clause and not otherwise recovered by or credited to the Government. (i) In the event of a partial termination, the portion of the fee which is payable with respect to the work under the continued portion of the contract shall be equitably adjusted by agreement between the Contractor and the Contracting Officer, and such adjustment shall be evidenced by an amendment to this contract. (j) The Government may from time to time, under such terms and conditions as it may prescribe, inake partial payments and payments on account against costs incurred by the Contractor in connection with the terminated portion of the contract whenever in the opinion of the Contracting Officer the aggregate of such payments shall be within the amount to which the Contractor will be entitled hereunder. If the total of such payments is in excess of the amount finally determined to be due under this clause, such excess shall be payable by the Contractor to the Government upon demand, together with interest computed at the rate established by the Secretary of the Treasury pursuant to Public Law 92-41; 85 STAT 97 for the Renegotiation Board, for the period from the date such excess payment is received by the Contractor to the date on which such excess is repaid to the Government; provided, however, that no interest shall be charged with respect to any such excess payment attributable to a reduction in the Contractor's claim by reason of retention or other disposition of termination inventory until 10 days after the date of such retention or disposition, or such later date as determined by the Contracting Officer by reason of the circumstances. (k) The provisions of this clause relating to the fee shall be inapplicable if this contract does not provide for payment of a fee. (End of clause) 7-203.10 ARMED SERVICES PROCUREMENT REGULATION CONTRACT CLAUSES AND SOLICITATION PROVISIONS 7-203.11 Excusable Delays. In accordance with 8-708, insert the following clause. EXCUSABLE DELAYS (1969 AUG) Except with respect to defaults of subcontractors the Contractor shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure by the Contractor to make progress in the prosecution of the work hereunder which endangers such performance) if such failure arises out of causes beyond the control and without the fault or negligence of the Contractor. Such causes may include, but are not restricted to: acts of God or of the public enemy; acts of the Government in either its sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes; freight embargoes; and unusually severe weather; but in every case the failure to perform must be beyond the control and without the fault or negligence of the Contractor. If the failure to perform is caused by the failure of a subcontractor to perform or make progress and if such failure arises out of causes beyond the control of both the Contractor and subcontractor, and without the fault or negligence of either of them, the Contractor shall not be deemed to be in default, unless (i) the supplies or services to be furnished by the subcontractor were obtainable from other sources (ii) the Contracting Officer shall have ordered the Contractor in writing to procure such supplies or services from such other sources, and (iii) the Contractor shall have failed to comply reasonably with such order. Upon request of the Contractor, the Contracting Officer shall ascertain the facts and extent of such failure and, if he shall determine that any failure to perform was occasioned by any one or more of the said causes, the delivery schedule shall be revised accordingly, subject to the rights of the Government under the clause hereof entitled “Termination.” (As used in this clause, the terms "subcontractor" and "subcontractors" mean subcontractor(s) at any tier.) (End of clause) 7-203.12 Disputes. Insert the clause in 7-103.12. 7-203.13 Renegotiation. In accordance with 7-103.13, insert the appropriate clause therein. 7-203.14 Commercial Bills of Lading Covering Shipment To or From Contractor's Plant. In accordance with 19-217.1(b), insert the following clause. COMMERCIAL BILL OF LADING NOTATIONS (1969 DEC) Prior to directing any shipment on a commercial bill of lading for which the Contractor will be reimbursed transportation costs as a direct allowable cost, the Contractor shall insure that the commercial shipping documents are annotated with either of the following notations, as appropriate: (i) when the Government is shown as the consignor or the consignee, the notation: (ii) when the Government will not be shown as the consignor or the consignee, the nota- "Transportation hereunder is for the U.S. Department of Defense, and the actual total transportation charges paid to the carrier(s) by the consignor or consignee are to be reimbursed by the Government pursuant to cost-reimbursable contract No. This may be confirmed by contacting ....................... (name and address of in the contract administration office listed in the contract such as DCASR, Detroit, Michigan, 1580 E. Grand Blvd., Detroit, Michigan 48211)." (End of clause) 7-203.15 Convict Labor. In accordance with 12-203, insert the clause in 7-104.17. 7-203.15 ARMED SERVICES PROCUREMENT REGULATION CONTRACT CLAUSES AND SOLICITATION PROVISIONS 7-203.16 Contract Work Hours and Safety Standards Act-Overtime Compensation. In accordance with 12-301, 12-302, and 12-306, insert the clauses in 7-103.16. 7-203.17 Walsh-Healey Public Contracts Act. In accordance with 12-602, insert the clause in 7-103.17. 7-203.18 Equal Opportunity. In accordance with 12-807.1, insert the plicable clause in 7-103.18. ap 7-203.19 Officials Not To Benefit. Insert the clause in 7-103.19. 7-203.20 Covenant Against Contingent Fees. Insert the clause in 7-103.20. 7-203.21 Government Property. Except in facilities contracts (see 13-101.11), insert the following clause when a Department is to furnish to the contractor, or the contractor is to acquire, Government property. GOVERNMENT PROPERTY (COST-REIMBURSEMENT) (1970 SEP) (a) Government-Furnished Property. The Government shall deliver to the Contractor, for use in connection with and under the terms of this contract, the property described as Governmentfurnished property in the Schedule or specifications, together with such related data and information as the Contractor may request and as may reasonably be required for the intended use of such property (hereinafter referred to as "Government-furnished property"). The delivery or performance dates for the supplies or services to be furnished by the Contractor under this contract are based upon the expectation that Government-furnished property suitable for use will be delivered to the Contractor at the times stated in the Schedule or, if not so stated, in sufficient time to enable the Contractor to meet such delivery or performance dates. In the event that Government-furnished property is not delivered to the Contractor by such time or times, the Contracting Officer shall, upon timely written request made by the Contractor, make a determination of the delay, if any, occasioned the Contractor and shall equitably adjust the estimated cost, fixed fee, or delivery or performance dates, or all of them, and any other contractual provisions affected by any such delay, in accordance with the procedures provided for in the clause of this contract entitled "Changes." In the event that Government-furnished property is received by the Contractor in a condition not suitable for the intended use, the Contractor shall, upon receipt thereof notify the Contracting Officer of such fact and, as directed by the Contracting Officer, either (i) return such property at the Government's expense or otherwise dispose of the property or (ii) effect repairs or modifications. Upon completion of (i) or (ii) above, the Contracting Officer upon written request of the Contractor shall equitably adjust the estimated cost, fixed fee, or delivery or performance dates, or all of them, and any other contractual provision affected by the return or disposition, or the repair or modification in accordance with the procedures provided for in the clause of this contract entitled “Changes." The foregoing provisions for adjustment are exclusive and the Government shall not be liable to suit for breach of contract by reason of any delay in delivery of Government-furnished property or delivery of such property in a condition not suitable for its intended use. (b) Changes in Government-Furnished Property. (1) By notice in writing, the Contracting Officer may (i) decrease the property furnished or to be furnished by the Government under this contract, or (ii) substitute other Governmentowned property for property to be furnished by the Government, or to be acquired by the Contractor for the Government, under this contract. The Contractor shall promptly take such action as the Contracting Officer may direct with respect to the removal and shipping of property covered by such notice. (2) In the event of any decrease in or substitution of property pursuant to paragraph (1) above, or any withdrawal of authority to use property provided under any other contract or lease, which property the Government had agreed in the Schedule to make available for the performance of this contract, the Contracting Officer, upon the written request of the Contractor (or, if the substitution of property causes a decrease in the cost of performance, on his own initiative), shall equitably adjust such contractual provisions as may be affected by the decrease, sub 7-203.21 ARMED SERVICES PROCUREMENT REGULATION CONTRACT CLAUSES AND SOLICITATION PROVISIONS stitution or withdrawal, in accordance with the procedures provided for in the “Changes" clause of this contract. (c) Title. Title to all property furnished by the Government shall remain in the Government. Title to all property purchased by the Contractor, for the cost of which the Contractor is entitled to be reimbursed as a direct item of cost under this contract, shall pass to and vest in the Government upon delivery of such property by the vendor. Title to other property, the cost of which is reimbursable to the Contractor under the contract, shall pass to and vest in the Government upon (i) issuance for use of such property in the performance of this contract, or (ii) commencement of processing or use of such property in the performance of this contract, or (iii) reimbursement of the cost thereof by the Government in whole or in part, whichever first occurs. All Government-furnished property, together with all property acquired by the Contractor title to which vests in the Government under this paragraph, are subject to the provisions of this clause and are hereinafter collectively referred to as “Government property." Title to the Government property shall not be affected by the incorporation or attachment thereof to any property not owned by the Government, nor shall such Government property, or any part thereof, be or become a fixture or lose its identity as personalty by reason of affixation to any realty. (d) Property Administration. The Contractor shall comply with the provisions of Appendix B, Armed Services Procurement Regulation, as in effect on the date of the contract, which is hereby incorporated by reference and made a part of this contract. Material to be furnished by the Government shall be ordered or returned by the Contractor, when required, in accordance with the "Manual for Military Standard Requisitioning and Issue Procedure (MILSTRIP) for Defense Contractors" (Appendix H, Armed Services Procurement Regulation) as in effect on the date of this contract, which Manual is hereby incorporated by reference and made a part of this contract. (e) Use of Government Property. The Government property shall, unless otherwise provided herein or approved by the Contracting Officer, be used only for the performance of this contract. (f) Utilization, Maintenance and Repair of Government Property. The Contractor shall maintain and administer, in accordance with sound industrial practice, and in accordance with applicable provisions of Appendix B, a program for the utilization, maintenance, repair, protection and preservation of Government property so as to assure its full availability and usefulness for the performance of this contract. The Contractor shall take all reasonable steps to comply with all appropriate directions or instructions which the Contracting Officer may prescribe as reasonably necessary for the protection of Government property. (g) Risk of Loss. (1) The Contractor shall not be liable for any loss of or damage to the Government property, or for expenses incidental to such loss or damage, except that the Contractor shall be responsible for any such loss or damage (including expenses incidental thereto): (i) which results from willful misconduct or lack of good faith on the part of any one of the Contractor's directors or officers, or on the part of any of his managers, superintendents, or other equivalent representatives, who has supervision or direction of: (A) all or substantially all of the Contractor's business; or (B) all or substantially all of the Contractor's operations at any one plant or separate location, in which this contract is being performed; or (C) a separate and complete major industrial operation in connection with the performance of this contract; (ii) which results from a failure on the part of the Contractor, due to the willful misconduct or lack of good faith on the part of any of his directors, officers, or other representatives mentioned in subparagraph (i) above (A) to maintain and administer, in accordance with sound industrial practice, the program for utilization, maintenance, repair, protection and preservation of Government property as required by paragraph (f) hereof, or to take all reasonable steps to comply with any appropriate written direction of the Contracting Officer under paragraph (f) hereof; or (B) to establish, maintain and administer, in accordance with (d) above, a system for control of Government property; (iii) for which the Contractor is otherwise responsible under the express terms of the clause or clauses designated in the Schedule; 7-203.21 ARMED SERVICES PROCUREMENT REGULATION |