The Code of Federal Regulations of the United States of AmericaU.S. Government Printing Office, 2005 - Administrative law The Code of Federal Regulations is the codification of the general and permanent rules published in the Federal Register by the executive departments and agencies of the Federal Government. |
From inside the book
Results 1-5 of 100
Page 15
... award document face page to the ref- erenced office prior to the day of award , or in sufficient time to allow for an announcement to be made by 5 p.m. Washington , DC time on the day of award . Subpart 305.5 - Paid Advertisements ...
... award document face page to the ref- erenced office prior to the day of award , or in sufficient time to allow for an announcement to be made by 5 p.m. Washington , DC time on the day of award . Subpart 305.5 - Paid Advertisements ...
Page 18
... award amount ; ( 3 ) Requested award date ; ( 4 ) Name and phone number of con- tact person ( usually the project offi- cer ) ; ( 5 ) Other information required for OPDIV needs . ( e ) Once the AAP is obtained , the contracting officer ...
... award amount ; ( 3 ) Requested award date ; ( 4 ) Name and phone number of con- tact person ( usually the project offi- cer ) ; ( 5 ) Other information required for OPDIV needs . ( e ) Once the AAP is obtained , the contracting officer ...
Page 20
... Award Instrument 307.7000 Scope of subpart . This subpart provides guidance on the appropriate selection of award in- struments consistent with 31 U.S.C. 6301-6308 . This subpart explains the use of the contract as the award instru ...
... Award Instrument 307.7000 Scope of subpart . This subpart provides guidance on the appropriate selection of award in- struments consistent with 31 U.S.C. 6301-6308 . This subpart explains the use of the contract as the award instru ...
Page 21
... award is to be made through the acquisition process or assistance process . This determination should be made prior to the time when the an- nual acquisition plan is reviewed and approved so that the plan will reflect all known proposed ...
... award is to be made through the acquisition process or assistance process . This determination should be made prior to the time when the an- nual acquisition plan is reviewed and approved so that the plan will reflect all known proposed ...
Page 27
... award a contract , or consent to a subcontract with a debarred or suspended contractor , the contracting officer shall prepare a de- termination , including all pertinent documentation , and submit it through acquisition channels to the ...
... award a contract , or consent to a subcontract with a debarred or suspended contractor , the contracting officer shall prepare a de- termination , including all pertinent documentation , and submit it through acquisition channels to the ...
Other editions - View all
Common terms and phrases
acceptable action Administration agency Alternate amount ance applicable approval authority cerns clude commercial competition Contract clauses contracting activity contracting officer Contractor copy debarment delegated delivery designated determination deviation document DOSAR End of clause evaluation exceed Federal Federal Acquisition Regulation following clause funds Government GSAR Indian Indian Act insert the clause insert the following inspection invoice July 11 July 9 labor lease Lessor ment notice OAMP offer offeror offi officer shall insert option paragraph payment performance Policy prescribed procedures Procurement Executive project officer proposal protest purchase quired real property receipt regulations request responsible Scope of subpart shipment simplified acquisition small business Solicitation provisions solicitations and contracts SOURCE specified subcontracting submitted supplies technical termination tion tracting officer tractor unless otherwise noted USDA
Popular passages
Page 79 - Contractor shall not be liable for any excess costs if the failure to perform the contract arises out of causes beyond the control and without the fault or negligence of the Contractor. Such causes may include, but are not restricted to, acts of God or of the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather; but in every case the failure to perform must...
Page 277 - Officer grants a further period of time before the date of final payment under the contract), notifies the Contracting Officer in writing of the causes of delay. The Contracting Officer shall ascertain the facts and the extent of the delay and extend the time for completing the work when, in his judgment, the findings of fact justify such an extension, and his findings of fact shall be final and conclusive on the parties, subject only to appeal as provided in Clause 6 of these General Provisions.
Page 225 - ... have access to and the right to examine any directly pertinent books, documents, papers, and records of such subcontractor, involving transactions related to the subcontract. The term "subcontract...
Page 52 - When an agency provides by a contract for the operation by or on behalf of the agency of a system of records to accomplish an agency function, the agency shall, consistent with its authority, cause the requirements of this section to be applied to such system.
Page 378 - XV Office of Administration, Executive Office of the President (Parts 2500—2599) XVI Office of Government Ethics (Parts 2600—2699) XXI Department of the Treasury (Parts 3100—3199...
Page 378 - Board of Governors of the Federal Reserve System (Part 6801) LIX National Aeronautics and Space Administration (Part 6901) LX United States Postal Service (Part 7001) LXI National Labor Relations Board (Part 7101) LXII Equal Employment Opportunity Commission (Part 7201...
Page 377 - Title 1— General Provisions I Administrative Committee of the Federal Register (Parts 1 — 49) II Office of the Federal Register (Parts 50—299) IV Miscellaneous Agencies (Parts...
Page 389 - CONTRACTS 50 Public Contracts, Department of Labor (Parts 50-1—50-999) 51 Committee for Purchase From People Who Are Blind or Severely Disabled (Parts 51-1—51-99) 60 Office of Federal Contract Compliance Programs, Equal Employment Opportunity, Department of Labor (Parts 60-1 — 60-999) 61 Office of the Assistant Secretary for Veterans...
Page 214 - ... contract upon an agreement or understanding for a commission, percentage, brokerage, or contingent fee, excepting bona fide employees or bona fide established commercial or selling agencies maintained by the Contractor for the purpose of securing business. For breach or violation of this warranty the Government shall have the right to annul this contract without liability or in its discretion to deduct from the contract price or consideration, or otherwise recover, the full amount of such commission,...
Page 262 - ... fit for the ordinary purposes for which such goods are used; and (d) run, within the variations permitted by the agreement, of even kind, quality and quantity within each unit and among all units involved; and (e) are adequately contained, packaged, and labeled as the agreement may require; and (f) conform to the promises or affirmations of fact made on the container or label if any.