Agency for International Development

ry in which the employees are working, or y the laws of the employee's native counry, whichever offers greater benefits.

(c) The Contractor further agrees to insert n all subcontracts hereunder to which the OBA is applicable, a clause similar to this lause, including this sentence, imposing on 11 subcontractors a like requirement to proide overseas workmen's compensation inFurance coverage and obtain DBA coverage under the A.I.D. requirements contract.

53 FR 50631, Dec. 16, 1988, as amended at 54 R 16122, Apr. 21, 1989; 56 FR 67226, Dec. 30, 991]

752.228-7 Insurance-liability to third persons.

As prescribed in 728.307-2(c), the following paragraph is to be added to the clause specified in FAR 52.228-7 as either paragraph (h) (if FAR 52.228-7 Alternate I is not used) or (i) (if FAR 52.228-7 Alternate I is used):

() Insurance on private automobiles. If the Contractor or any of its employees or their dependents transport or cause to be transported (whether or not at contract expense) privately owned automobiles to the Cooperating Country, or they or any of them purchase an automobile within the Cooperating Country, the Contractor agrees to make certain that all such automobiles during such ownership within the Cooperating Country will be covered by a paid-up insurance policy issued by a reliable company providing the following minimum coverages or such other minimum coverages as may be set by the Mission Director, payable in United States dollars or its equivalent in the currency of the Cooperating Country: injury to persons, $10,000/$20,000; property damage, $5,000. The premium costs for such insurance shall not be a reimbursable cost under this contract. Copies of such insurance policies shall be preserved and made available as part of the Contractor's records which are required to be preserved and made available by the "Examination of Records by the Comptroller General" and "Audit" clauses of this contract.

[53 FR 50632, Dec. 16, 1988, as amended at 54 FR 16122, Apr. 21, 1989]

752.228-9 Cargo insurance.

As prescribed in 728.313(a), the following preface is to be used preceding the text of the clause at FAR 52.228-9:

PREFACE: To the extent that marine insurance is necessary or appropriate under this contract, the contractor shall ensure that U.S. marine insurance companies are offered a fair opportunity to bid for such insurance.

MEDICAL EVACUATION (MEDEVAC) SERVICES (MAR 1993)

(a) Contractors agree to provide medevac service coverage to all U.S. citizen, U.S. resident alien, and Third Country National employees and their authorized dependents while overseas under an AID financed direct contract. Coverage shall be obtained pursuant to the terms of the contract between AID and AID's medevac service provider unless exempted in accordance with paragraph (b) of this clause.

(b) The following are exempted from the requirements in paragraph (a) of this clause:

(1) Eligible employees and their dependents with a health program that includes sufficient medevac coverage as approved by the Contracting Officer.

(ii) Eligible employees and their dependents located at Missions where the Mission Director makes a written determination to waive the requirement for such coverage based on findings that the quality of local medical services or other circumstances obviate the need for such coverage.

(c) Contractors further agree to insert in all subcontracts hereunder to which the medevac coverage is applicable, a clause similar to this clause, including this sentence, imposing on all subcontractors a like requirement to provide medical evacuation services coverage and obtain medevac coverage in accordance with the contract between AID and AID's medevac service provider.

[59 FR 33447, June 29, 1994]

752.229-70 Federal, state and local taxes.

For contracts involving performance overseas the clauses prescribed in FAR 29.401-3 or 29.401-4 may be modified to specify that the taxes referred to are United States taxes.

752.232-7 Payments under time-and

materials and labor-hour contracts.

AID uses the payment provision contained in FAR 52.232-7 in indefinite quantity contracts for professional services up to 120 days, as provided in AIDAR 716.501(c). When this provision

is used the following preamble will be included:

For the purposes of this clause certain terms shall be interpreted as follows:

The term "contract(s)" includes "delivery order(s)"; "hour(s)”, or “hourly" may be calculated in terms of "day(s)" or "daily (8 hours)"; and "materials" includes "other direct costs".

[50 FR 11450, Apr. 3, 1986]

752.232-70 Letter of credit advance payment.

As required by 732.406-73 insert the following clause in contracts being paid by Letter of Credit.

LETTER OF CREDIT ADVANCE PAYMENT (OCT. 1989)

(a) Payment under this contract shall be by means of a Letter of Credit (LOC) in accordance with the terms and conditions of the LOC and any instructions issued by the AID Office of Financial Management, Cash Management and Payment Division (FM/ CMP).

(b) As long as the LOC is in effect, the terms and conditions of the LOC and any instructions issued by FM/CMP constitute the payment conditions of this contract, superseding and taking precedence over any other clause of this contract concerning payment.

(c) If the LOC is revoked, payment may be made on a cost-reimbursement basis, in accordance with the other clauses of this contract concerning payment.

(d) Revocation of the LOC is at the discretion of FM/CMP after consultation with the contracting officer. Notification to the contractor of revocation must be in writing and must specify the reasons for such action. The contractor may appeal any such revocation to the contracting officer, in accordance with the Disputes clause of this contract. Pending final decision, payments under the contact will be in accordance with paragraph (c) of this clause.

[49 FR 13259, Apr. 3, 1984, as amended at 49 FR 33668, Aug. 24, 1984; 54 FR 46391, Nov. 3, 1989; 56 FR 67226, Dec. 30, 1991; 59 FR 33447, June 29, 1994]

752.245-70 Government property-AID reporting requirements.

In response to a GAO audit recommendation, AID contracts must contain the following preface and reporting requirement as additions to the appropriate Government Property clause prescribed by FAR 45.106.

Preface: to be inserted preceding the text of the FAR clause.

The term "Government furnished property" wherever it may appear in the following clause, shall mean (1) non-expendable personal property owned by or leased to the U.S. Government and furnished to the contractor and (2) personal property furnished either prior to or during the performance of this contract by any U.S. Government accountable officer to the contractor for use in connection with performance of this contract and identified by such officer as accountable. The term "government property", wherever it may appear in the following clause, shall mean government-furnished property and non-expendable personal property title to which vests in the U.S. Government under this contract. Non-expendable property, for purposes of this contract, is defined as property which is complete in itself, does not lose its identity or become a component part of another article when put into use; is durable, with an expected service life of two years or more; and which has a unit cost of more than $500.

Reporting Requirement: to be inserted following the text of the FAR clause.

Reporting Requirements: The contractor will submit an annual report on all non-expendable property in a form and manner acceptable to AID substantially as follows:

3 Explain if transactions were not processed through or otherwise authorized by AID.

PROPERTY INVENTORY VERIFICATIONS

I attest that (1) physical inventories of Government property are taken not less frequently than annually; (2) the accountability records maintained or Government property in our possession are in agreement with such inventories; and (3) the total of the detailed accountability records maintained agrees with the property value shown opposite line C above, and the estimated average age of each category of property is as cited opposite line D above.

Authorized Signature

752.245-71 Title to and care of property.

It is AID policy to vest title with the cooperating country for contractor acquired property used in a cooperating country. The following clause is for use in all AID contracts under which the contractor will acquire property for use overseas under the contract.

TITLE TO AND CARE OF PROPERTY (APR. 1984)

(a) Title to all non-expendable property purchased with contract funds under this contract and used in the Cooperating Country, shall at all times be in the name of the Cooperating Government, or such public or private agency as the Cooperating Government may designate, unless title to specified types or classes of non-expendable property is reserved to AID under provisions set forth in the schedule of this contract; but all such property shall be under the custody and control of Contractor until the owner of title directs otherwise, or completion of work under this contract or its termination, at which time custody and control shall be turned over to the owner of title or disposed of in accordance with its instructions. All performance guaranties and warranties obtained from suppliers shall be taken in the name of the title owner. (Non-expendable property is property which is complete in itself, does not lose its identity or become a component part of another article when put into use; is durable, with an expected service life of two years or more; and which has a unit cost of $500 of more.)

(b) Contractor shall prepare and establish a program, to be approved by the Mission, for the receipt, use, maintenance, protection, custody, and care of non-expendable property for which it has custodial responsibility, including the establishment of reasonable controls to enforce such program.

(c)(1) For non-expendable property to which title is reserved to the U.S. Government under provisions set forth in the sched

ule of this contract, Contractor shall submit an annual report on all non-expendable property under its custody as required in the clause of this contract entitled "Government Property".

(2) For non-expendable property titled to the Cooperating Government, the Contractor shall, within 90 days after completion of this contract, or at such other date as may be fixed by the Contracting Officer, submit an inventory schedule covering all items of nonexpendable property under its custody, which have not been consumed in the performance of this contract. The Contractor shall also indicate what disposition has been made of such property.

Subpart 752.70-Texts of AID Contract Clauses

752.7000 Scope of subpart.

Subpart 752.70 contains the text of AID-specific contract clauses for which there is no FAR equivalent. The clauses in this Subpart do not apply to contracts for personal services. For personal service contract clauses see AIDAR Appendix D-Direct AID Contracts with U.S. Citizens or U.S. Residents for Personal Services Abroad and AIDAR Appendix J-Direct AID Contracts with Cooperating Country Nationals and with Third Country Nationals for Personal Services Abroad.

[49 FR 13259, Apr. 3, 1984, as amended at 57 FR 5237, Feb. 13, 1992]

752.7001 Biographical data.

This clause is required in all AID contracts.

BIOGRAPHICAL DATA (DEC. 1988)

(a) The Contractor agrees to furnish to the Contracting Officer on AID Form 1420-17, "Contractor Employee Biographical Data Sheet", biographical information on the following individuals to be employed in the performance of the contract: (1) All individuals to be sent outside of the United States, (2) any employees designated as "key personnel". Biographical data in the form usually maintained by the Contractor on the other individuals employed under the contract shall be available for review by A.I.D. at the Contractor's headquarters. A supply of AID Form 1420-17 will be provided with this contract. The Contractor may reproduce additional copies as necessary.

(b) Emergency locator information. The Contractor agrees to provide the following information to the Mission Administrative Officer on or before the arrival in the host

country of every contract employee or dependent:

(1) The individual's full name, home address, and telephone number.

(2) The name and number of the contract, and whether the individual is an employee or dependent.

(3) The contractor's name, home office address, and telephone number, including any after-hours emergency number(s), and the name of the contractor's home office staff member having administrative responsibility for the contract.

(4) The name, address, and telephone number(s) of each individual's next of kin.

(5) Any special instructions pertaining to emergency situations such as power of attorney designees or alternate contact persons. [49 FR 13259, Apr. 3, 1984, as amended at 53 FR 50632, Dec. 16, 1988]

752.7002 Travel and transportation.

For use in cost reimbursement contracts performed in whole or in part overseas.

TRAVEL AND TRANSPORTATION (JAN. 1990) (a) General. The Contractor will be reimbursed for reasonable, allocable and allowable travel and transportation expenses incurred under and for the performance of this contract. Determination of reasonableness, allocability and allowability will be made by the Contracting Officer based on the applicable cost principles, the Contractor's established policies and procedures, AID's established policies and procedures for AID directhire employees, and the particular needs of the project being implemented by this contract. The following paragraphs provide specific guidance and limitations on particular items of cost.

(b) International travel. For travel to and from post of assignment the Contractor shall be reimbursed for travel costs and travel allowances of travelers from place of residence in the United States (or other location provided that the cost of such travel does not exceed the cost of the travel from the employee's residence in the United States) to the post of duty in the Cooperating Country and return to place of residence in the United States (or other location provided that the cost of such travel does not exceed the cost of travel from the post of duty in the Cooperating Country to the employee's residence) upon completion of services by the individual. Reimbursement for travel will be in accordance with the applicable cost principles and the provisions of this contract, and will be limited to the cost of travel by the most direct and expeditious route. If a regular employee does not complete one full year at post of duty (except for reasons beyond his/her control), the costs of going to

and from the post of duty for that employee and his/her dependents are not reimbursable hereunder. If the employee serves more than one year but less than the required service in the Cooperating Country (except for reasons beyond his/her control) the costs of going to the post of duty are reimbursable hereunder but the costs of going from post of duty to the employee's permanent, legal place of residence at the time he or she was employed for work under this contract or other location as approved by the Contracting Officer are not reimbursable under this contract for the employee and his/her dependents. When travel is by economy class accommodations, the Contractor will be reimbursed for the cost of transporting up to 22 pounds of accompanied personal baggage per traveler in addition to that regularly allowed with the economy ticket provided that the total number of pounds of baggage does not exceed that regularly allowed for first class travelers. Travel allowances for travelers shall not be in excess of the rates authorized in the Standardized Regulations (Government Civilians, Foreign Areas)-hereinafter referred to as the Standardized Regulations-as from time to time amended, for not more than the travel time required by scheduled commercial air carrier using the most expeditious route. One stopover en route for a period of not to exceed 24 hours is allowable when the traveler uses economy class accommodations for a trip of 14 hours or more of scheduled duration. Such stopover shall not be authorized when travel is by indirect route or is delayed for the convenience of the traveler. Per diem during such stopover shall be paid in accordance with the established practice of the Contractor but not to exceed the amounts stated in the Standardized Regulations.

(c) Local travel. Reimbursement for local travel in connection with duties directly referable to the contract shall not be in excess of the rates established by the Mission Director for the travel costs of travelers in the Cooperating Country. In the absence of such established rates the Contractor shall be reimbursed for actual travel costs of travelers in the Cooperating Country, if not provided by the Cooperating Government or the Mission, including travel allowances at rates not in excess of those prescribed by the Standardized Regulations.

(d) Travel for consultation. The Contractor shall be reimbursed for the round trip of the Contractor's Chief of Party in the Cooperating Country or other designated Contractor employee or consultant in the Cooperating Country performing services required under this Contract, for travel from the Cooperating Country to the Contractor's office in the United States or to AID/Washington for consultation and return on occasions deemed necessary by the Contractor and approved in

advance, in writing, by the Contracting Officer or the Mission Director.

(e) Special international travel and third country travel. For special travel which advances the purpose of the contract, which is not otherwise provided by the Cooperating Government, and with the prior written approval of the Contracting Officer or the Mission Director, the Contractor shall be reimbursed for (i) the travel cost of travelers other than between the United States and the Cooperating Country and for local travel within other countries and (ii) travel allowance for travelers while in travel status and while performing services hereunder in such other countries at rates not in excess of those prescribed by the Standardized Regulations.

(f) Indirect travel for personal convenience. When travel is performed by an indirect route for the personal convenience of the traveler, the allowable costs of such travel will be computed on the basis of the cost of allowable air fare via the direct usually traveled route. If such costs include fares for air or ocean travel by foreign flag carriers, approval for indirect travel by such foreign flag carriers must be obtained from the Contracting Officer or the Mission Director before such travel is undertaken, otherwise only that portion of travel accomplished by United States-flag carriers will be reimbursable within the above limitation of allowable costs.

(g) Limitation on travel by dependents. Travel costs and allowances will be allowed only for dependents of regular employees and such costs shall be reimbursed for travel from place of abode to assigned station in the Cooperating Country and return, only if dependent remains in the country for at least 9 months or one-half of the required tour of duty of the regular employee responsible for such dependent, whichever is greater. If the dependent is eligible for educational travel pursuant to the "Differential and Allowances" clause of this contract, time spent away from post resulting from educational travel will be counted as time at post.

(h) Delays en route. The Contractor may grant to travelers under this contract reasonable delays en route while in travel status when such delays are caused by events beyond the control of such traveler or Contractor. It is understood that if delay is caused by physical incapacitation, personnel shall be eligible for such sick leave as provided under the "Leave and Holidays" clause of this contract.

(1) Travel by privately owned automobile. The Contractor shall be reimbursed for the cost of travel performed by a regular employee in his/her privately owned automobile at a rate not to exceed that authorized in the Federal Travel Regulations plus authorized per diem for the employee and for each of the authorized dependents traveling in the automobile,

if the automobile is being driven to or from the Cooperating Country as authorized under the contract, provided that the total cost of the mileage and the per diem paid to all authorized travelers shall not exceed the total constructive cost of fare and normal per diem by all authorized travelers by surface common carrier or authorized air fare, whichever is less.

(j) Emergency and irregular travel and transportation. Emergency transportation costs and travel allowances while en route, as provided in this section will also be reimbursed not to exceed amounts authorized by the Foreign Service Travel Regulations for AIDdirect hire employees in like circumstances under the following conditions:

(1) The costs of going from post of duty in the Cooperating Country to the employee's permanent, legal place of residence at the time he or she was employed for work under this contract or other location for Contractor employees and dependents and returning to the post of duty, when the Contractor's Chief of Party, with the concurrence of the Contracting Officer or Mission Director makes a written determination that such travel is necessary for one of the reasons specified in subparagraphs (j)(1) (i) and (ii) of this section. A copy of the written determination shall be furnished to the Contracting Officer.

(1) Need for medical care beyond that available within the area to which the employee is assigned, or serious effect on physical or mental health if residence is continued at assigned post of duty, subject in either case, to the limitations stated in the clause of this contract entitled "PersonnelPhysical Fitness of Employee and Dependents." The Mission Director may authorize a medical attendant to accompany the employee at contract expense if, based on medical opinion, such an attendant is necessary. (ii) Death, or serious illness or injury of a member of the immediate family of the employee or the immediate family of the employee's spouse.

(2) When, for any reason, the Mission Director determines it is necessary to evacuate the Contractor's entire team (employees and dependents) or Contractor dependents only, the Contractor will be reimbursed for travel and transportation expenses and travel allowance while en route, for the cost of the individuals going from post of duty in the Cooperating Country to the employee's permanent, legal place of residence at the time he or she was employed for work under this contract or other approved location. The return of such employees and dependents may also be authorized by the Mission Director when, in his/her discretion, he/she determines it is prudent to do so.

(3) The Mission Director may also authorize emergency or irregular travel and transportation in other situations, when in his/her