The Code of Federal Regulations of the United States of America

Front Cover
U.S. Government Printing Office, 1983 - Administrative law
The Code of Federal Regulations is the codification of the general and permanent rules published in the Federal Register by the executive departments and agencies of the Federal Government.

From inside the book

Other editions - View all

Common terms and phrases

Popular passages

Page 160 - ... or retained to solicit or secure this Contract upon an agreement or understanding for a commission, percentage, brokerage, or contingent fee, excepting bona fide employees or bona fide established commercial or selling agencies maintained by the Contractor for the purpose of securing business. For breach or violation of this warranty the Government shall have the right to annul this Contract without liability or in its discretion to deduct from the contract price or consideration, or otherwise...
Page 188 - Any claim by the contractor for adjustment under this clause must be asserted within thirty (30) days from the date of receipt by the contractor of the notification of change; Provided, however, That the contracting officer, if he decides that the facts justify such action, may receive and act upon any such claim asserted at any time prior to final payment under this contract. Failure to agree to any adjustment shall be a dispute concerning a question of fact within the meaning of the clause of this...
Page 258 - Officer grants a further period of time before the date of final payment under the contract), notifies the Contracting Officer in writing of the causes of delay. The Contracting Officer shall ascertain the facts and the extent of the delay and extend the time for completing the work when, in his judgment, the findings of fact justify such an extension...
Page 55 - ... or delivery schedule, or both, and the contract shall be modified in writing accordingly. Any claim by the Contractor for adjustment under this clause must be asserted within 30 days from the date of receipt by the Contractor of the notification of change: Provided^, however, That the Contracting Officer, if he decides that the facts justify such action, may receive and act upon any such claim asserted at any tune prior to final payment under this contract.
Page 246 - Regulation, as it may be amended from time to time, the Contractor may submit to the Contracting Officer a list, certified as to quantity and quality, of any or all items of termination inventory not previously disposed of, exclusive of items the disposition of which has been directed or authorized by the Contracting Officer, and may request the Government to remove such items or enter into a storage agreement covering them. Not later than fifteen...
Page 252 - Officer may, subject to any review required by the contracting agency's procedures in effect as of the date of execution of this contract, determine, on the basis of information available to him, the amount, if any, due to the Contractor by reason of the termination and shall thereupon pay to the Contractor the amount so determined. (d) Subject to the provisions of paragraph (c), and subject to any review required by the contracting agency's procedures in effect as of...
Page 642 - Part 8 in effect as of the date of execution of this contract, the Contractor and the Contracting Officer may agree upon the whole or any part of the amount or amounts to be paid to the Contractor by reason of the total or partial termination of work pursuant to this clause, which amount or amounts may include a reasonable allowance for profit on work done: Provided, That such agreed amount or amounts...
Page 242 - Disputes," from any determination made by the Contracting Officer under paragraph (c) or (e) above, except that if the Contractor has failed to submit his claim within the time provided in paragraph (c) above and has failed to request extension of such time, he shall have no such right of appeal. In any case where the Contracting Officer has made a determination of the amount due under paragraph (c) or (e) above, the Government shall pay to the Contractor the following...
Page 174 - Regulations in effect as of the date of execution of this contract, determine, on the basis of Information available to him, the amount, if any, due to the Contractor by reason of the termination and shall thereupon pay to the Contractor the amount so determined. (d) Subject to the provisions of paragraph (c) , and subject to any Settlement Review Board approvals required by NASA Regulations in effect as of...
Page 241 - Officer may direct; (viii) complete performance of such part of the work as shall not have been terminated by the Notice of Termination; and (ix) take such action as may be necessary, or as the Contracting Officer may direct, for the protection and preservation of the property related to this contract which is in the possession of the Contractor and in which the Government has or may acquire an interest.

Bibliographic information