Sec.

10-60.203 Treasury representation before General Services Administration Board of Contract Appeals.

10-60.204 Effective date.

AUTHORITY: 63 Stat. 390, 40 U.S.C. 486(c); 5 U.S.C. 301.

SOURCE: 32 FR 8676, June 16, 1967, unless otherwise noted.

§ 10-60.100 Treasury contract appeals to be heard by General Services Administration Board of Contract Appeals.

The General Services Administration Board of Contract Appeals (herein called the Board), with the prior approval of the Administrator of General Services, hereby is designated the authorized representative of the Secretary of the Treasury in hearing, considering, and determining as fully and finally as might the Secretary, all appeals by contractors from final decisions by contracting officers on disputed questions taken pursuant to the provisions of contracts (other than contracts of the Office of the Comptroller of the Currency) requiring the determination of such appeals by the Secretary or his duly authorized representative.

§ 10-60.200 Rules regarding contract dispute appeals.

The rules and regulations pertaining to the appeal of General Services Administration contract disputes prescribed in or pursuant to Part 5-60 of this title and this part shall govern the appeal of all contract disputes with the Department of the Treasury, or with any bureau, office (other than the Office of the Comptroller of the Currency), division or other agency or subdivision of the Department of the Treasury, except for the rules entitled "Notice of appeal" (Rule 1, § 5-60.201 of this title), “Request, preparation and submission" (pertaining to the appeal file) (Rule 4A(1), § 5-60.204-1 of this title), and "Payment of claims" (Rule 22, § 5-60.224 of this title). Wherever the rules of the GSA Board in Subpart 5-60.2 of this title refer to the General Services Administration (or GSA) or the Administrator or the General Counsel, GSA, there shall be substituted the terms Treasury De

partment, the Secretary or the General Counsel, Treasury Department, respectively.

§ 10-60.201 Notice of appeal.

§ 10-60.201-1 Filing.

A notice of appeal must be in writing, and shall be filed with the office of the contracting officer from whose decision the appeal is taken. The notice of appeal must be mailed or otherwise filed with the contracting officer within the time specified therefor in the contract, or as allowed in applicable provisions of directives or law.

§ 10-60.201-2 Forwarding of appeals.

When a notice of appeal in any form has been received by the contracting officer, he shall endorse thereon the date of mailing and the date of receipt (or the date of receipt only, if otherwise conveyed) and within 20 days shall forward said notice of appeal, together with the envelope in which same was enclosed, to the Board, with a copy to the General Counsel, Treasury Department, Washington, D.C. 20220. Following receipt by the Board of the original notice of appeal (whether through the contracting officer or otherwise), the contractor, the contracting officer, and General Counsel, Treasury Department, will be advised promptly thereof, and the contractor will be furnished a copy of the Board's rules.

§ 10-60.202 Appeal file.

Following receipt of a notice of appeal, the contracting officer shall

promptly, and in any event within 30 days, compile and transmit to the General Counsel, Treasury Department, two (2) copies of the appeal file as prescribed in Rule 4A(2), § 5-60.2042 of this title. The General Counsel will submit the appeal file to the Board as promptly as possible after receipt by him of the Board's request therefor, and in any event so as to reach the Board within 45 days after such receipt.

§ 10-60.203 Treasury representation before General Services Administration Board of Contract Appeals.

The General Counsel of the Treasury Department will assure representation of the interests of the Government in proceedings before the General Services Administration Board of Contract Appeals. All officers and employees of the Treasury Department will appear and give testimony as required and will cooperate with the General Services Administration Board of Contract Appeals and Government counsel in the processing of appeals so as to assure their speedy and just determination.

§ 10-60.204 Effective date.

The regulations in this part shall become effective on the date of publiIcation in the FEDERAL REGISTER. The regulations in this part shall apply to all cases now pending or in which appeal from the contracting officer's decision is taken on or after the effective date.

Subpart 12-1.3-General Policies

12-1.302-3 Contracts between the Government and Government employees or business concerns substantially owned or controlled by Government employees. 12-1.305-3 Deviations from Federal specifications.

12-1.305-50 Index to Federal and Depart

ment of Defense Specifications and Standards.

12-1.306-1 Mandatory use and application of Federal Standards.

12-1.307-5 Limitations on use of "brand name or equal" purchase descriptions. 12-1.311 Priorities, allocations and allotments.

12-1.313 Records of contract actions. 12-1.315 Use of liquidated damages provisions in procurement contracts. 12-1.315-2 Policy.

12-1.318 Disputes clause.

12-1.318-50 Contracting officer's decision under the disputes clause.

12-1.318-51

filed.

Agreement after appeal is

12-1.318-52 Payment after appeal is filed. 12-1.318-53 Implementation of decisions of the Contract Appeals Board. 12-1.320 Subcontractor gifts and kick

backs.

12-1.351 Contract number prefixes.