The Code of Federal Regulations of the United States of America

Front Cover
U.S. Government Printing Office, 1965 - Administrative law
The Code of Federal Regulations is the codification of the general and permanent rules published in the Federal Register by the executive departments and agencies of the Federal Government.

From inside the book

Selected pages

Other editions - View all

Common terms and phrases

Popular passages

Page 212 - Contractor for the purpose of securing business. For breach or violation of this warranty the Government shall have the right to annul this contract without liability, or In Its discretion to deduct from the contract price or consideration, or otherwise recover, the full amount of such commission, percentage, brokerage, or contingent fee.
Page 208 - The Contracting Officer may at any time, by a written order, and without notice to the sureties, make changes, within the general scope of this contract, in any one or more of the following...
Page 253 - In the event that Governmentfurnished Property Is not delivered to the Contractor by such time or times, the Contracting Officer shall, upon timely written request made by the Contractor, make a determination of the delay occasioned the Contractor thereby, and shall equitably adJust the delivery or performance dates or the contract price, or both, and any other contractual provision affected by such delay. In accordance with the procedures provided for In the clause of this contract entitled "Changes.
Page 193 - Contractor's failure to perform or to make progress in performance is due to causes beyond the control and without the fault or negligence of the Contractor pursuant to the provisions of the clause of this contract relating to excusable delays, the Notice of Termination...
Page 264 - Disputes" clause does not preclude consideration of law questions in connection with decisions provided for in paragraph (a) above: Provided, That nothing in this contract shall be construed as making final the decision of any administrative official, representative, or board on a question of law.
Page 215 - ... hostile or warlike action, including action in hindering, combating, or defending against an actual, impending, or expected attack...
Page 143 - States, or if articles, materials, or supplies of the class or kind to be used or the articles, materials, or supplies from which they are manufactured are not mined, produced, or manufactured, as the case may be, in the United States in sufficient and reasonably available commercial quantities and of a satisfactory quality.
Page 264 - Pending final decision of a dispute hereunder, the Contractor shall proceed diligently with the performance of the contract and in accordance with the Contracting Officer's decision. b. This "Disputes...
Page 275 - Government under this contract; and (ii) a release discharging the Government, its officers, agents, and employees from all liabilities, obligations, and claims arising out of or under this contract, subject only to the following exceptions...
Page 264 - Except as otherwise provided in this contract, any dispute concerning a question of fact arising under this contract which is not disposed of by agreement shall be decided by the Contracting Officer, who shall reduce his decision to writing and mail or otherwise furnish a copy thereof to the Contractor.

Bibliographic information