Code of Federal Regulations: Containing a Codification of Documents of General Applicability and Future Effect as of December 31, 1948, with Ancillaries and IndexU.S. General Services Administration, National Archives and Records Service, Office of the Federal Register, 1978 - Administrative law Special edition of the Federal Register, containing a codification of documents of general applicability and future effect ... with ancillaries. |
From inside the book
Results 1-5 of 100
Page 16
... bids or proposals as individuals on appropriate procure- ments . Bids or proposals submitted by an individual member of a pool shall not be considered when the individual member has participated in the bid or proposal submitted by the ...
... bids or proposals as individuals on appropriate procure- ments . Bids or proposals submitted by an individual member of a pool shall not be considered when the individual member has participated in the bid or proposal submitted by the ...
Page 21
... bids , " brand name or equal " descriptions . or ( a ) Except as provided in ( b ) of this § 1-1.307-6 when a " brand name equal " purchase description is includ- ed in an invitation for bids : ( 1 ) The following shall be inserted ...
... bids , " brand name or equal " descriptions . or ( a ) Except as provided in ( b ) of this § 1-1.307-6 when a " brand name equal " purchase description is includ- ed in an invitation for bids : ( 1 ) The following shall be inserted ...
Page 22
... Bids will not be considered . ( b ) Where a component part of an end item is described in the invitation for bids by a " brand name or equal ” purchase description and the contract- ing officer determines that application of the clause ...
... Bids will not be considered . ( b ) Where a component part of an end item is described in the invitation for bids by a " brand name or equal ” purchase description and the contract- ing officer determines that application of the clause ...
Page 24
... bids and an appropriate rate ( s ) of liquidated damages ( deter- mined pursuant to § 1-1.315-2 ) shall be stipulated : LIQUIDATED DAMAGES Article 11 ( f ) of Standard Form 32 , Gener- al Provisions ( Supply Contract ) , is redesig ...
... bids and an appropriate rate ( s ) of liquidated damages ( deter- mined pursuant to § 1-1.315-2 ) shall be stipulated : LIQUIDATED DAMAGES Article 11 ( f ) of Standard Form 32 , Gener- al Provisions ( Supply Contract ) , is redesig ...
Page 25
... bids or offers , and for awarding contracts . ( h ) Time for contractors to comply with any conditions precedent to per- formance . ( i ) Time for the Government to per- form its obligations under the contract ( e.g. , furnishing of ...
... bids or offers , and for awarding contracts . ( h ) Time for contractors to comply with any conditions precedent to per- formance . ( i ) Time for the Government to per- form its obligations under the contract ( e.g. , furnishing of ...
Other editions - View all
Common terms and phrases
accordance adjustment ADPE agree agreement allocation amended amount ance applicable appropriate assets authorized award basis bidder business unit Buy American Act cation cerns certificate clause set cluding contract clauses contract price contracting officer Contractor cost accounting period Cost Accounting Standards cost objectives cost or pricing curement delivery determination disclosure ernment estimated executive agencies Federal fixed-price furnished G&A expense Government property home office Insert the clause invention inventory invitation for bids jewel bearings July 24 labor surplus area liability material ment negotiated notice offeror otherwise overhead rates paragraph patent payment pension cost performance prescribed pricing data prime contract prior procedures procuring agency proposal purchase pursuant quired reasonable receipt regulations request Schedule set-aside settlement small business concerns solicitation specific Standard Form subcon subcontract submitted supplies termination tion tracting officer tractor
Popular passages
Page 350 - The decision of the Secretary or his duly authorized representative for the determination of such appeals shall be final and conclusive unless determined by a court of competent jurisdiction to have been fraudulent, or capricious, or arbitrary, or so grossly erroneous as necessarily to imply bad faith, or not supported by substantial evidence.
Page 408 - Contractor for adjustment under this clause must be asserted within 30 days from the date of receipt by the Contractor of the notification of change: Provided, however, That the Contracting Officer, if he decides that the facts justify such action, may receive and act upon any such claim asserted at any time prior to final payment under this contract. Failure to agree to any adjustment shall be a dispute concerning a question of fact within the meaning of the clause of this contract entitled "Disputes.
Page 454 - ... the Government may, by written notice to the contractor, terminate his right to proceed with the work or such part of the work as to which there has been delay. In...
Page 348 - Contracting Officer" means the person executing this contract on behalf of the Government, and any other officer or civilian employee who Is a properly designated Contracting Officer; and the term Includes, except as otherwise provided In this contract, the authorized representative of a Contracting Officer acting within the limits of his authority. (c) 'Except as otherwise provided In this contract, the term "subcontracts" Includes purchase orders under this contract.
Page 322 - Consequential damages resulting from the seller's breach include (a) any loss resulting from general or particular requirements and needs of which the seller at the time of contracting had reason to know and which could not reasonably be prevented by cover or otherwise; and (b) injury to person or property proximately resulting from any breach of warranty.
Page 350 - ... fraudulent, or capricious, or arbitrary, or so grossly erroneous as necessarily to Imply bad faith, or not supported by substantial evidence. In connection with any appeal proceeding under this clause, the Contractor shall be afforded an opportunity to be heard and to offer evidence In support of Its appeal. Pending final decision of a dispute hereunder, the Contractor shall proceed diligently with the performance of the contract and in accordance with the Contracting Officer's decision. (b)...
Page 441 - Government to the Contractor under this contract or shall otherwise be credited to the price or cost of the work covered by this contract or paid in such other manner as the Contracting Officer may direct; (8) Complete performance of such part of the work as shall not have been terminated by the Notice of Termination; and (9) Take such action as may be necessary, or as the Contracting Officer may direct, for the protection and preservation of the property related to this contract which is in the...
Page 348 - Where the cost of property made obsolete or excess as a result of a change is included in the Contractor's claim for adjustment, the Contracting Officer shall have the right to prescribe the manner of disposition of such property. Failure to agree to any adjustment shall be a dispute concerning a question of fact within the meaning of the clause of this contract entitled "Disputes.
Page 383 - Any claim by the Contractor for adjustment under this clause must be asserted within 30 days from the date of receipt by the Contractor of the notification of change: Provided, however, That the Contracting Officer, if he decides that the facts justify such action, may receive and act upon any such claim asserted at any time prior to final payment under this contract.
Page 339 - domestic source end product" means (A) an unmanufactured end product which has been mined or produced in the United States and (B) an end product manufactured in the United States if the cost of the components thereof which are mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components.