Cases Decided in the United States Court of Claims ... with Report of Decisions of the Supreme Court in Court of Claims Cases, Volume 126The Court, 1954 - Law reports, digests, etc |
From inside the book
Results 1-5 of 90
Page 34
... concrete structures at the Riverton project in Wyoming . Under the contract specifications the Government agreed to furnish cement , reinforcing steel and certain other 34 Opinion of the Court materials for use in the 34 W. E. BARLING.
... concrete structures at the Riverton project in Wyoming . Under the contract specifications the Government agreed to furnish cement , reinforcing steel and certain other 34 Opinion of the Court materials for use in the 34 W. E. BARLING.
Page 36
... concrete structures for defendant at the Riverton Project in Wyoming . The contract specifications contained a provision that defendant would furnish certain materials , including cement and reinforcing steel , for use in the com ...
... concrete structures for defendant at the Riverton Project in Wyoming . The contract specifications contained a provision that defendant would furnish certain materials , including cement and reinforcing steel , for use in the com ...
Page 37
... concrete placing operations because of a lack of cement . 2 Plaintiff applied for and was granted an extension of time because of the inability and failure of defendant to furnish cement and steel as needed . The contracting officer ...
... concrete placing operations because of a lack of cement . 2 Plaintiff applied for and was granted an extension of time because of the inability and failure of defendant to furnish cement and steel as needed . The contracting officer ...
Page 40
... concrete structures for a pilot canal , laterals and sublaterals , which were a part of the defendant's Pilot Division , Riverton Project , Wyoming . 4. The contract provided that the work should be begun within 30 calendar days after ...
... concrete structures for a pilot canal , laterals and sublaterals , which were a part of the defendant's Pilot Division , Riverton Project , Wyoming . 4. The contract provided that the work should be begun within 30 calendar days after ...
Page 43
... concrete , mortar , and grout ; admixtures , if required , for use in concrete , mortar , and grout ; reinforcement bars ; pre- cast lock - joint concrete pipe for siphons , turnouts , and culverts ; lumber for permanent installation in ...
... concrete , mortar , and grout ; admixtures , if required , for use in concrete , mortar , and grout ; reinforcement bars ; pre- cast lock - joint concrete pipe for siphons , turnouts , and culverts ; lumber for permanent installation in ...
Other editions - View all
Common terms and phrases
action additional agreed agreement alleged amended amount appeal April arsenic Article asserted attorney August base course Borg-Warner calendar days canteens Chippewa claim Commissioner Company completed concrete construction contract price contracting officer contractor Corporation cost Court December December 14 decision defendant delay delivered delivery Department Depot determined dismissed entitled to recover equipment evidence excess profits tax February February 28 filed Findings of Fact follows furnish Government contract Howard Aircraft Corporation Indians Internal Revenue issued January January 19 Judge July June Khoongs letter Leyte liquidated damages loss Lucas Act manufacture ment Navy negotiations November November 18 October operations Opinion paid paragraph parties patent payment performance period petition piers plaintiff pleading prior pursuant radar Ranslow relief request Rule September September 15 settlement ships specifications Stat subgrade submitted summary judgment termination thereof tiff tion tract Treaty unit price vessel Warren E Wemp
Popular passages
Page 869 - (2) General Rule. — If. during the taxable year, the recognized gains upon sales or exchanges of property used In the trade or business, plus the recognized gains from the compulsory or involuntary conversion (as a result of destruction In whole or In part, theft or seizure, or an exercise of the power of requisition or condemnation or the threat or imminence thereof) of property used In the trade or business...
Page 16 - When issues not raised by the pleadings are tried by express or implied consent of the parties, they shall be treated in all respects as if they had been raised in the pleadings. Such amendment of the pleadings as may be necessary to cause them to conform to the evidence and to raise these issues may be made upon motion of any party at any time, even after judgment; but failure so to amend does not affect the result of the trial of these issues.
Page 13 - Every defense, in law or fact, to a claim for relief in any pleading, whether a claim, counterclaim, cross-claim, or third-party claim, shall be asserted in the responsive pleading thereto if one is required, except that the following defenses may at the option of the pleader be made by motion...
Page 48 - A party may interrogate any unwilling or hostile witness by leading questions. A party may call an adverse party or an officer, director, or managing agent of a public or private corporation or of a partnership or association which is an adverse party, and interrogate him by leading questions and contradict and impeach him in all respects as if he had been called by the adverse party, and the witness thus called may be contradicted and impeached by or on behalf of the adverse party also, and may...
Page 605 - No Indian nation or tribe, within the territory of the United States, shall be acknowledged or recognized as an independent nation, tribe, or power with whom the United States may contract by treaty...
Page 33 - Any party may take the testimony of any person, including a party, by deposition upon oral examination or written interrogatories for the purpose of discovery or for use as evidence in the action or for both purposes.
Page 16 - If evidence is objected to at the trial on the ground that it is not within the issues made by the pleadings, the court may allow the pleadings to be amended and shall do so freely when the presentation of the merits of the action will be subserved thereby and the objecting party fails to satisfy the court that the admission of such evidence would prejudice him in maintaining his action or defense upon the merits.
Page 2 - In computing any period of time prescribed or allowed by these rules, by order of court, or by any applicable statute, the day of the act, event, or default after which the designated period of time begins to run is not to be included.
Page 15 - A pleading shall state as a counterclaim any claim which at the time of serving the pleading the pleader has against any opposing party, if it arises out of the transaction or occurrence that is the subject matter of the opposing party's claim and does not require for its adjudication the presence of third parties of whom the court cannot acquire jurisdiction...
Page 33 - Parties may obtain discovery regarding any matter, not privileged, which is relevant to the subject matter involved in the pending action, whether it relates to the claim or defense of the party seeking discovery or to the claim or defense of any other party...