Orders and Regulations, Corps of Engineers, U.S. Army, 1934U.S. Government Printing Office, 1934 |
From inside the book
Results 1-5 of 90
Page 11
... copy will be returned to the contracting officer and the third copy retained by the contractor . Proceeding before approval of bonds . It is not necessary to delay commencement under the contract pending approval of bonds by The Judge ...
... copy will be returned to the contracting officer and the third copy retained by the contractor . Proceeding before approval of bonds . It is not necessary to delay commencement under the contract pending approval of bonds by The Judge ...
Page 12
... copy of U. S. Standard Form No. 1036 intended for the General Accounting Office or a copy thereof securely attached to that form . 7102.17 Contract Cost Principles Attention is particularly directed to the provisions of Section XV of ...
... copy of U. S. Standard Form No. 1036 intended for the General Accounting Office or a copy thereof securely attached to that form . 7102.17 Contract Cost Principles Attention is particularly directed to the provisions of Section XV of ...
Page 12
... Copies of letters of contracting officer authority or revocation will not be forwarded to the Chief of Engi- Following is a sample of the context of a letter delegating contracting officer authority : Under authority of paragraph ...
... Copies of letters of contracting officer authority or revocation will not be forwarded to the Chief of Engi- Following is a sample of the context of a letter delegating contracting officer authority : Under authority of paragraph ...
Page 12
... copy of each such designation will be immediately submitted to contractors concerned . g . Contracting officer authority of commanding of ficers of engineer depots and engineer supply officers at other depots . Commanding officers of ...
... copy of each such designation will be immediately submitted to contractors concerned . g . Contracting officer authority of commanding of ficers of engineer depots and engineer supply officers at other depots . Commanding officers of ...
Page 14
... copy of the record of negotiation . Contracts Requiring Approval of the Chief of Engineers 7103.10 Subject to the requirements of the preceding paragraph , the following con- tracts will be executed subject to the approval of the Chief ...
... copy of the record of negotiation . Contracts Requiring Approval of the Chief of Engineers 7103.10 Subject to the requirements of the preceding paragraph , the following con- tracts will be executed subject to the approval of the Chief ...
Other editions - View all
Common terms and phrases
80th Congress agree amount appeal applicable approval architect-engineer Army ARTICLE ASPR assignment authorized representative award bidder bill of lading Board CHANGE 16 change order Chapter VII Chief of Engineers claim classifications completion construction contracts Contract Form contractor copy corporation cost damage Davis-Bacon Act delay Department Deputy Contracting Officer determined District Engineers Division Engineer employee ENG Form equipment estimated excess executed facilities Federal findings of fact fixed fee funds furnished Government GSUSA hereby hereunder insert Instructions job order labor lessee liquidated damages lump sum construction materials ment modified necessary negotiated paid paragraph parties hereto payment performance person prescribed principal contract prior purchase order pursuant rates rental request schedule Secretary Secretary of Labor Special Protective specifications Standard Form subcontract submitted supplemental agreement supplies terminated thereof tion tract tractor United wage War Department War Powers Act
Popular passages
Page 177 - Government may take over the work and prosecute the same to completion by contract or otherwise, and the contractor and his sureties shall be liable to the Government for any excess cost occasioned the Government thereby.
Page 121 - ... supplies as have been mined or produced in the United States, and only such manufactured articles, materials, and supplies as have been manufactured in the United States substantially all from articles, materials, or supplies mined, produced, or manufactured, as the case may be, in the United States, shall be acquired for public use.
Page 177 - ... unforeseeable causes beyond the control and without the fault or negligence of the Contractor, including, but not restricted to, acts of God, or of the public enemy, acts of the Government...
Page 164 - ... the Government may, by written notice to the contractor, terminate his right to proceed with the work or such part of the work as to which there has been a failure to pay...
Page 164 - CHANGES The Contracting Officer may at any time, by a written order, and without notice to the sureties, make changes in the drawings and/or specifications of this contract and within the general scope thereof.
Page 3 - No executive department or other Government establishment of the United States shall expend, in any one fiscal year, any sum in excess of appropriations made by Congress for that fiscal year, or involve the Government in any contract or other obligation for the future payment of money in excess of such appropriations unless such contract or obligation is authorized by law.
Page 111 - Federal lending agency, and may thereafter be further assigned and reassigned to any such institution. Any such assignment or reassignment shall cover all amounts payable under this contract and not already paid, and shall not be made to more than one party, except that any such assignment or reassignment may be made to one party as agent or trustee for two or more parties participating in such financing.
Page 102 - Government under this contract may be assigned to a bank, trust company, or other financing institution, including any Federal lending agency, and may thereafter be further assigned and reassigned to any such institution.
Page 192 - America, hereinafter called the Government, represented by the contracting officer executing this contract, and a corporation organized and existing under the laws of the State of a partnership consisting of an individual trading as of the city of in the State of hereinafter called the contractor, witnesseth that the parties hereto do mutually agree as follows: Article 1.
Page 198 - Except as otherwise specifically provided in this contract, all disputes concerning questions of fact arising under this contract shall be decided by the contracting officer subject to written appeal by the contractor within 30 days to the head of the department concerned or his duly authorized representative, whose decision shall be final and conclusive upon the parties thereto. In the meantime the contractor shall diligently proceed with the work as directed.