Cases Decided in the United States Court of Claims ... with Report of Decisions of the Supreme Court in Court of Claims Cases, Volume 116The Court, 1950 - Law reports, digests, etc |
From inside the book
Results 1-5 of 100
Page 2
... con- ditions as found upon doing the excavating , plaintiffs were not misled by defendant even if plaintiffs ' engineers concluded from 1 Syllabus the information given that only two deep gorges 2 SILAS MASON COMPANY , INC . , ET AL .
... con- ditions as found upon doing the excavating , plaintiffs were not misled by defendant even if plaintiffs ' engineers concluded from 1 Syllabus the information given that only two deep gorges 2 SILAS MASON COMPANY , INC . , ET AL .
Page 8
... Engineer , Bureau of Reclamation , as contracting officer , to furnish labor and materials , and perform all work required for con- struction of Grand Coulee Dam and Power Plant as covered by items 1 to 85 inclusive , of the schedule of ...
... Engineer , Bureau of Reclamation , as contracting officer , to furnish labor and materials , and perform all work required for con- struction of Grand Coulee Dam and Power Plant as covered by items 1 to 85 inclusive , of the schedule of ...
Page 9
... engineer and representative of the contracting officer on the job , was on the site for some time prior to the letting of the contract and was there during the period of work under the contract . 7. Before the contract was let the ...
... engineer and representative of the contracting officer on the job , was on the site for some time prior to the letting of the contract and was there during the period of work under the contract . 7. Before the contract was let the ...
Page 19
... specifications . Be- ginning in the early summer of 1936 the plaintiffs had con- ferences with the construction engineer and other of defend- 116 C. Cls . Reporter's Statement of the Case ant's SILAS MASON COMPANY , INC . , ET AL . 19.
... specifications . Be- ginning in the early summer of 1936 the plaintiffs had con- ferences with the construction engineer and other of defend- 116 C. Cls . Reporter's Statement of the Case ant's SILAS MASON COMPANY , INC . , ET AL . 19.
Page 20
... engineer asking for an interpretation of the applicable provisions of the specifications , and pointing out practices of inspectors which plaintiffs considered to be unnecessary , and made complaint that they were required to remove ...
... engineer asking for an interpretation of the applicable provisions of the specifications , and pointing out practices of inspectors which plaintiffs considered to be unnecessary , and made complaint that they were required to remove ...
Other editions - View all
Common terms and phrases
accordance acres action actual additional agreed allowed amount appeal applicable approved authorized basis Board building cause change order charge claim Company compensation completion concrete construction contained contracting officer contractor Corporation cost Court covered damages December decision defendant defendant's delay Department determined directed drawings effect engineer entered entitled equipment evidence excavation fact feet filed findings follows forms furnished further Government grout held Housing increased Indians installed interest issued January Judge judgment July June labor land letter lumber March material ment necessary November October operation Opinion paid paragraph parties patent payment performed period petition placed plaintiff plant prior purchase question railroad reasonable received record recover referred removal Reporter's Statement representative reservation result rock schedule September Shipping shown specifications Stat suit tion United vessel yard
Popular passages
Page 360 - Contractor, including, but not restricted to, acts of God, or of the public enemy, acts of the Government...
Page 397 - No person who holds an office the salary or annual compensation attached to which amounts to the sum of two thousand five hundred dollars shall be appointed to or hold any other office to which compensation is attached unless specially heretofore or hereafter specially authorized thereto by law...
Page 359 - Officer in writing of: (1) subsurface or latent physical conditions at the site differing materially from those indicated in this contract, or (2) unknown physical conditions at the site, of an unusual nature, differing materially from those ordinarily encountered and generally recognized as inhering in work of the character provided for in this contract.
Page xx - To confer jurisdiction upon the Court of Claims to hear, determine, and render judgment upon the claim of Herbert M.
Page 514 - Is permitted only upon the condition that every such laborer and mechanic shall be compensated for all hours worked In excess of eight hours per day at not less than one and one-half times the basic rate of pay.
Page 575 - The Emergency Court of Appeals, and the Supreme Court upon review of judgments and orders of the Emergency Court of Appeals, shall have exclusive jurisdiction to determine the validity of any regulation or order issued under section 2...
Page 295 - ... remission or mitigation of such fine, penalty, or forfeiture, the Secretary of the Treasury, or the Secretary of Commerce, if he finds that such fine, penalty, or forfeiture was incurred without willful negligence or without any intention on the part of the petitioner to defraud the revenue or to violate the law...
Page 221 - If the Contractor refuses or fails to prosecute the work, or any separable part thereof, with such diligence as will insure its completion within the time specified in this contract, or any extension thereof, or fails to complete said work within such time, the Government may, by written notice to the Contractor, terminate his right to proceed with the work or such part of the work as to which there has been delay.
Page 671 - No interest shall be allowed on any claim up to the time of the rendition of judgment by the Court of Claims, unless upon a contract expressly stipulating for the payment of interest...
Page 746 - In the event It Is found by the contracting officer that any laborer or mechanic employed by the contractor or any subcontractor directly on the site of the work covered by the contract has been or is being paid a rate of wages less than the rate of wages required by the contract to be paid...