Cases Decided in the United States Court of Claims ... with Report of Decisions of the Supreme Court in Court of Claims Cases, Volume 152The Court, 1963 - Law reports, digests, etc |
From inside the book
Results 1-5 of 100
Page 69
... construction of a quay wall , piers and mooring platforms at the San Francisco Naval Shipyard , on the ground that the delays which occasioned extra costs incurred by the contractor were caused by the Government's negligent and wrongful ...
... construction of a quay wall , piers and mooring platforms at the San Francisco Naval Shipyard , on the ground that the delays which occasioned extra costs incurred by the contractor were caused by the Government's negligent and wrongful ...
Page 70
... construction of a quay wall , piers , and mooring platforms at the San Francisco Naval Shipyard . Plaintiff's bid of $ 4,251,198 was accepted by letter dated June 25 , 1946 , and by the same letter defendant directed plaintiff to ...
... construction of a quay wall , piers , and mooring platforms at the San Francisco Naval Shipyard . Plaintiff's bid of $ 4,251,198 was accepted by letter dated June 25 , 1946 , and by the same letter defendant directed plaintiff to ...
Page 71
... construction of the quay wall and piers could commence . To enable plaintiff to begin work , it was necessary that the dredging work be completed in the area from the shoreline past the quay wall site to about one - fourth of the ...
... construction of the quay wall and piers could commence . To enable plaintiff to begin work , it was necessary that the dredging work be completed in the area from the shoreline past the quay wall site to about one - fourth of the ...
Page 72
... construction of the quay wall was delayed 154 calendar days after January 20 , 1947 , the date when the site first became available , and until June 24 , 1947 , when defendant first supplied sufficient piles necessary for commencement ...
... construction of the quay wall was delayed 154 calendar days after January 20 , 1947 , the date when the site first became available , and until June 24 , 1947 , when defendant first supplied sufficient piles necessary for commencement ...
Page 78
... construction of the quay wall , de- fendant failed to exercise reasonable diligence to provide the piles in the order in which they would be required for use on the project . Defendant cites the case of Barling v . United States , 126 ...
... construction of the quay wall , de- fendant failed to exercise reasonable diligence to provide the piles in the order in which they would be required for use on the project . Defendant cites the case of Barling v . United States , 126 ...
Other editions - View all
Common terms and phrases
action active duty agreement aluminum amount approval Army assets August Beam Bureau Canal claim Commission Commissioner Company computed contract 955 Contracting Officer Contractor corporation Correction Board cost Court 152 Ct defendant defendant's determined disability retired District dredging easement excess profits excess profits tax Fact 152 Ct filed Findings of Fact follows Freedom Fair Government income interest Internal Revenue Internal Revenue Code January January 18 Judge judgment July June June 27 Kaiser land lease lessee letters of intent liability Liberty ships Maritime Maritime Commission ment military Navy November October October 20 October 31 operation Opinion paid percent period petition physical disability piles plaintiff plants prior pursuant quay wall received record refund requested res judicata retired list retired pay Reynolds riprap rocky fill Sea Trader ships Sol Goldenberg Stat statute summary judgment termination tion transfer Troutdale United vessels Wiegand
Popular passages
Page 466 - ... Corporations, and any community chest, fund, or foundation, organized and operated exclusively for religious, charitable, scientific, testing for public safety, literary, or educational purposes, or for the prevention of cruelty to children or animals, no part of the net earnings of which inures to the benefit of any private shareholder or individual, no substantial part of the activities of which is carrying on propaganda, or otherwise attempting, to influence legislation, and which does not...
Page 206 - All transfers and assignments made of any claim upon the United States, or of any part or share thereof, or interest therein, whether absolute or conditional, and whatever may be the consideration therefor, and all powers of attorney, orders, or other authorities for receiving payment of any such claim, or of any part or share thereof, shall be absolutely null and void...
Page 207 - ... after the allowance of such a claim, the ascertainment of the amount due and the issuing of a warrant for the payment thereof.
Page 171 - The rights and remedies of the Government provided in this clause shall not be exclusive and are In addition to any other rights and remedies provided by law or under this contract.
Page 37 - Take such action as may be necessary, or as the Contracting Officer may direct, for the protection and preservation of the property related to this contract which is in the possession of the Contractor and In whicn the Government has or may acquire an interest.
Page 833 - In the case of a failure to make and file a declaration of estimated tax within the time prescribed, unless such failure is shown to the satisfaction of the Commissioner to be due to reasonable cause and not to willful neglect...
Page 38 - Such claim shall be submitted promptly but in no event later than one year from the effective date of termination, unless one or more extensions in writing are granted by the Contracting Officer, upon request of the Contractor made in writing within such one year period or authorized extension thereof.
Page 41 - Contractor, from the effective date of termination and for a period of three years after final settlement under this contract, shall preserve and make available to the Government at all reasonable times at the...
Page 37 - ... terminate all orders and subcontracts to the extent that they relate to the performance of work terminated by the Notice of Termination...
Page 16 - The performance of work under this contract may be terminated by the Government in accordance with this clause in whole, or from time to time in part, whenever the Contracting Officer shall determine that such termination is in the best interest of the Government.