The Code of Federal Regulations of the United States of America
U.S. Government Printing Office, 1976 - Administrative law
The Code of Federal Regulations is the codification of the general and permanent rules published in the Federal Register by the executive departments and agencies of the Federal Government.
Other editions - View all
accepted accordance agreement amount applicable approval Architect-Engineer ARMED SERVICES PROCUREMENT ASPR authorized award bond certified claim clause therein CLAUSES AND SOLICITATION completed computer software contract price Contracting Officer Contractor agrees cordance Cost Accounting Standards damage DD Form default delivered delivery determined End of clause equipment equitable adjustment extent Facilities fixed-price following clause furnished Government property hereunder incurred insert the clause insert the following invoice liability license materials ment modification negotiated Notice of Termination notify the Contracting offeror otherwise paid paragraph percent performance period pricing data prime contractor prior procedures PROCUREMENT REGULATION CONTRACT production progress payments proposal purchase pursuant quantity rates reasonable receipt REGULATION CONTRACT CLAUSES reimbursed request Schedule Section SERVICES PROCUREMENT REGULATION settlement shipment small business concerns SOLICITATION PROVISIONS specified subcontract Subject Invention submitted supplies or services surety technical data thereof tion tracting Officer tractor unit price VECP
Page 325 - USC 15), if this contract provides for payments aggregating $1,000 or more, claims for moneys due or to become due the Contractor from the Government under this contract may be assigned to a bank, trust company, or other financing institution, including any Federal lending agency, and may thereafter be further assigned and reassigned to any such institution. Any such assignment or reassignment shall cover all amounts payable under this contract and not already paid, and shall not be made to more...
Page 64 - Disputes" clause does not preclude consideration of law questions in connection with decisions provided for in paragraph a above; provided, that nothing in this contract shall be construed as making final the decision of any administrative official, representative, or board on a question of law.
Page 71 - The Contractor warrants that no person or selling agency has been employed or retained to solicit or secure this contract upon an agreement or understanding for a commission, percentage, brokerage, or contingent fee, excepting bona fide employees or bona fide established commercial or selling agencies maintained by the Contractor for the purpose of securing business. For breach or violation of this warranty the Government shall have the right to annul this contract without liability or in its discretion...
Page 322 - Officer grants a further period of time before the date of final payment under the contract), notifies the Contracting Officer in writing of the causes of delay. The Contracting Officer shall ascertain the facts and the extent of the delay and extend the time for completing the work when, in his judgment, the findings of fact justify such an extension, and his findings of fact shall be final and conclusive on the parties subject only to appeal as provided in the clause of this contract entitled "Disputes.
Page 71 - Cancel, terminate, or suspend in whole or in part this grant (contract, loan, Insurance, guarantee); refrain from extending any further assistance to the applicant under the program with respect to which the failure or refusal occurred until satisfactory assurance of future compliance has been received from such applicant; and refer the case to the Department of Justice for appropriate legal proceedings.
Page 500 - Any claim by the Contractor for adjustment under this clause must be asserted within 30 days from the date of receipt by the Contractor of the notification of change: Provided, however, That the Contracting Officer, if he decides that the facts Justify such action, may receive and act upon any such claim asserted at any time prior to final payment under this contract.
Page 290 - Contractor for adjustment under this clause must be asserted within thirty (30) days from the date of receipt by the Contractor of the notification of change; provided, however, that the Contracting Officer, if he decides that the facts justify such action, may receive and act upon any such claim asserted at any time prior to final payment under this contract. Failure to agree to any adjustment shall be a dispute concerning a question of fact within the meaning of the clause of this contract entitled...
Page 304 - Title to Government property shall not be affected by the incorporation or attachment thereof to any property not owned by the Government, nor shall such Government property, or any part thereof, be or become a fixture or lose its identity as personalty by reason of affixation to any realty.
Page 112 - Property, caused by an excepted peril, it shall equitably reimburse the Government. The Contractor shall do nothing to prejudice the Government's rights to recover against third parties for any such loss, destruction, or damage and, upon the request of the Contracting Officer, shall at the Government's expense, furnish to the Government all reasonable assistance and cooperation (including the prosecution of suit and the execution of instruments of assignment in favor of the Government) in obtaining...
Page 381 - Regulation, as it may be amended from time to time, the Contractor may submit to the Contracting Officer a list, certified as to quantity and quality, of any or all items of termination inventory not previously disposed of, exclusive of items the disposition of which has been directed or authorized by the Contracting Officer, and may request the Government to remove such items or enter into a storage agreement covering them. Not later than fifteen...