The Code of Federal Regulations of the United States of AmericaU.S. Government Printing Office, 1979 - Administrative law The Code of Federal Regulations is the codification of the general and permanent rules published in the Federal Register by the executive departments and agencies of the Federal Government. |
From inside the book
Results 1-5 of 100
Page 25
... notice of award to arrive through the ordinary mails . ( 2 ) The foregoing delivery requirements are based on the assumption that the suc- cessful bidder will receive that notice of award by ( procuring activity insert calendar date ) ...
... notice of award to arrive through the ordinary mails . ( 2 ) The foregoing delivery requirements are based on the assumption that the suc- cessful bidder will receive that notice of award by ( procuring activity insert calendar date ) ...
Page 28
... notice of appeal ( in triplicate ) addressed to the ( Title of the head of the agency ) is mailed or otherwise furnished to the Contracting Officer . The notice of appeal , which is to be signed by you as the contractor or by an ...
... notice of appeal ( in triplicate ) addressed to the ( Title of the head of the agency ) is mailed or otherwise furnished to the Contracting Officer . The notice of appeal , which is to be signed by you as the contractor or by an ...
Page 50
... Notice of suspension . A firm or individual that has been suspended shall be furnished immedi- ately with a notice of the suspension , by registered mail , by the head of the agency or his designee . The notice of suspension shall state ...
... Notice of suspension . A firm or individual that has been suspended shall be furnished immedi- ately with a notice of the suspension , by registered mail , by the head of the agency or his designee . The notice of suspension shall state ...
Page 52
... notice of debarment ( at time of issu- ance ) on those debarments made under provisions of § 1-1.604 ( a ) , or the Buy American Act , and provide GSA with information as to any removals of such debarments . ( d ) Check the list of ...
... notice of debarment ( at time of issu- ance ) on those debarments made under provisions of § 1-1.604 ( a ) , or the Buy American Act , and provide GSA with information as to any removals of such debarments . ( d ) Check the list of ...
Page 66
... notice of appeal . However , the appellant shall submit to the SBA Size Appeals Board an original and four legible copies of such notice and , to avoid time - consuming correspondence , the notice should include the follow- ing ...
... notice of appeal . However , the appellant shall submit to the SBA Size Appeals Board an original and four legible copies of such notice and , to avoid time - consuming correspondence , the notice should include the follow- ing ...
Other editions - View all
Common terms and phrases
accordance adjustment Administration ADPE agree agreement allocation amended amount ance applicable appropriate assets authorized award basis bidder Buy American Act cerns certificate clause set cluding contract clauses contract price contracting officer Contractor cost accounting period Cost Accounting Standards cost objectives cost or pricing cost-reimbursement curement delivery determination disclosure employees ernment erwise estimated executive agencies exemption Federal fixed-price furnished Government property home office Insert the clause invention invitation for bids jewel bearings July 24 labor surplus area liability material ment negotiated notice offeror otherwise paragraph patent payment performance prescribed pricing data prime contractor prior procedures procuring agency proposal Puerto Rico purchase pursuant quired rates reasonable receipt regulations request settlement small business concerns solicitation specific subcon subcontract submitted Subpart supplies termination tion tracting officer tractor
Popular passages
Page 396 - Except as otherwise provided in this contract, any dispute concerning a question of fact arising under this contract which is not disposed of by agreement shall be decided by the Contracting Officer, who shall reduce his decision to writing and mail or otherwise furnish a copy thereof to the Contractor.
Page 396 - Jurisdiction to have been fraudulent, or capricious, or arbitrary, or so grossly erroneous as necessarily to Imply bad faith, or not supported by substantial evidence. In connection with any appeal proceeding under this clause, the Contractor shall be afforded an opportunity to be heard and to offer evidence in support of Its appeal. Pending final decision of a dispute hereunder, the Contractor shall proceed diligently with the performance of the contract and In accordance with the Contracting Officer's...
Page 35 - For purposes of this section, the term "agency" as defined in section 551(1) of this title includes any executive department, military department, Government corporation, Government controlled corporation, or other establishment in the executive branch of the Government (including the Executive Office of the President), or any independent regulatory agency. § 552a. Records Maintained on Individuals (a) Definitions. For purposes of this section— (1) the term "agency...
Page 493 - ... and at a price or prices approved by the Contracting Officer: And provided further, That the proceeds of any such transfer or disposition shall be applied in reduction of any payments to be made by the Government to the Contractor under this contract or shall otherwise be credited to the price or cost of the work covered by this contract or paid in such other manner as the Contracting Officer may direct; (8) Complete performance of such part of the work as shall not have been terminated by the...
Page 78 - UTILIZATION OF SMALL BUSINESS CONCERNS (a) It is the policy of the Government as declared by the Congress that a fair proportion of the purchases and contracts for supplies and services for the Government be placed with small business concerns. (b) The Contractor agrees to accomplish the maximum amount of subcontracting to small business concerns that the Contractor finds to be consistent with the efficient performance of this contract. [End of Clause] (b) The Small Business Subcontracting Program...
Page 563 - Invention or discovery" includes any art, machine, manufacture, design, or composition of matter, or any new and useful improvement thereof, or any variety of plant, which is or may be patentable under the patent laws of the United States of America or any foreign country.
Page 427 - Contractor for adjustment under this clause must be asserted within thirty (30) days from the date of receipt by the Contractor of the notification of change; provided, however, that the Contracting Officer, if he decides that the facts justify such action, may receive and act upon any such claim asserted at any time prior to final payment under this contract. Failure to agree to any adjustment shall be a dispute concerning a question of fact within the meaning of the clause of this contract entitled...
Page 509 - Article 1, or any extension thereof, or fails to complete said work within such time, the Government may, by written notice to the contractor, terminate his right to proceed with the work or such part of the work as to which there has been delay.
Page 621 - The Contractor will furnish all information and reports required by Executive Order No. 11246 of September 24. 1965, and by the rules, regulations, and orders of the Secretary of Labor, or pursuant thereto, and will permit access to his books, records, and accounts by the contracting agency and the Secretary of Labor for purposes of Investigation to ascertain compliance with such rules, regulations, and orders.
Page 621 - Equal Opportunity clause of this contract or with any of the said rules, regulations, or orders, this contract may be canceled, terminated, or suspended, in whole or in part, and the Contractor may be declared ineligible for further Government contracts in accordance with procedures authorized in Executive Order No. 11246 of September 24, 1965, and such other sanctions may be imposed and remedies invoked as provided in Executive Order No. 11246 of September 24, 1965, or by rule, regulation, or order...