The Code of Federal Regulations of the United States of America

Front Cover
U.S. Government Printing Office, 1975 - Administrative law
The Code of Federal Regulations is the codification of the general and permanent rules published in the Federal Register by the executive departments and agencies of the Federal Government.

From inside the book

Other editions - View all

Common terms and phrases

Popular passages

Page 298 - Except as otherwise provided in this contract, any dispute concerning a question of fact arising under this contract which is not disposed of by agreement shall be decided by the Contracting Officer, who shall reduce his decision to writing and mail or otherwise furnish a copy thereof to the Contractor.
Page 293 - Subsurface or latent physical conditions at the site differing materially from those Indicated in this contract, or (2) unknown physical conditions at the site, of an unusual nature. differing materially from those ordinarily encountered and generally recognized as Inhering in work of the character provided for in this contract.
Page 122 - Consequential damages resulting from the seller's breach include (a) any loss resulting from general or particular requirements and needs of which the seller at the time of contracting had reason to know and which could not reasonably be prevented by cover or otherwise; and (b) injury to person or property proximately resulting from any breach of warranty.
Page 259 - In this contract, or any extension thereof, or fails to complete said work within such time, the Government may, by written notice to the Contractor, terminate his right to proceed with the work or such part of the work as to which there has been delay. In such event the Government may take over the work and prosecute the same to completion, by contract or otherwise, and may take possession of and utilize in completing the work such materials, appliances, and plant as may be on the site of the work...
Page 159 - Title to all property furnished by the Government shall remain in the Government. Title to all property purchased by the Contractor, the cost of which the Contractor is entitled to be reimbursed as a direct item of cost under this Contract, shall pass to and vest in the Government upon delivery of such property by the vendor.
Page 94 - Contractor for adjustment under this clause must be asserted within 30 days from the date of receipt by the Contractor of the notification of change. Provided, however, That the Contracting Officer, if he decides that the facts justify such action, may receive and act upon any such claim asserted at any time prior to final payment under this contract.
Page 103 - The Contractor shall not be reimbursed for, and shall not include as an item of overhead, the cost of insurance or any provision for a reserve, covering the risk of loss of or damage to the Government property, except to the extent that the Government may have required the Contractor to carry such insurance under any other provision of this contract.
Page 149 - Contractor inventory means (1) any property acquired by and in the possession of a contractor or subcontractor (including Government-furnished property) under a contract pursuant to the terms of which title is vested in the Government, and in excess of the amounts needed to complete full performance under the entire contract; and...
Page 125 - ... to perform their services at any location, under his control, where segregated facilities are maintained. He certifies further that he will not maintain or provide for his employees any segregated facilities at any of his establishments, and that he will not permit his employees to perform their services at any location, under his control, where segregated facilities are maintained. The...
Page 260 - The delay in the completion of the work arises from unforeseeable causes beyond the control and without the fault or negligence of the Contractor, including but not restricted to, acts of God, acts of the public enemy, acts of the Government in either its sovereign or contractual capacity, acts of another contractor in the performance of a contract with the Government, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, unusually severe weather, or delays of subcontractors...

Bibliographic information